PALAU

EIGHT OLBIIL ERA KELULAU
First Special Session, March 2009
RPPL NO. 8-19
(Intro. As House Bill No. 8-19-1S, HD2, SD2)

AN ACT

To amend Title 39 of the Palau National Code to include a new Chapter 9 to establish a condominium law that will give statutory recognition to the condominium form of ownership of real property and establish procedures for the creation, sale, and operation of condominiums, and for related purposes. 

THE PEOPLE OF PALAU REPRESENTED IN THE OLBIIL ERA KELULAU DO ENACT AS FOLLOWS: 
 
Section 1. Short Title. This Act shall be known and may be cited as the "Palau Condominium Property Act of 2010." 

Section 2. Legislative Findings. The Olbiil Era Kelulau finds substantial potential for condominium development in the Republic of Palau, and finds the need for a legal framework that encourages that development. It is sound public policy for such a framework to protect condominium ownership rights, define the legal relationship among the various parties involved in condominium development and ownership, and establish a set of guidelines by which owners make collective decisions and resolve conflicts. Consistent with this policy, this Bill creates a condominium property right - called a horizontal property regime - and establishes the process by which a developer declares that right; it establishes the law governing condominium associations; it defines the rights and remedies of owners and lessees; it defines the rights and obligations of condominium developers; and it governs the legal relationship between condominium developers and the unit owners. The Olbiil Era Kelulau finds this Bill will establish the necessary rights and legal processes that will create a stable, predictable system for condominium ownership and management, and will thus encourage the development of condominiums in the Republic. 

Section 3. Amendment. Title 39 of the Palau National Code is hereby amended to add a new Chapter 9 as follows: 

"Chapter 9
Condominiums

PART I
GENERAL PROVISIONS

§ 901. Definitions. As used in this chapter, the term:

(1) "Assessment" means a share of the funds which are required for the payment of common expenses, which from time to time is assessed against the unit owner. 

(2) "Association" means, in addition to any entity responsible for the operation of common elements owned in undivided shares by unit owners, any entity which operates or maintains other real property in which unit owners have use rights, where membership in the entity is composed exclusively of unit owners or their elected or appointed representatives and is a required condition of unit ownership. 

(3) "Association property" means that property, real and personal, which is owned or leased by, or is dedicated by a recorded plat to, the association for the use and benefit of its members. 

(4) "Board of administration" or "board" means the board of directors or other representative body which is responsible for administration of the association. 

(5) "Buyer" means a person who purchases a condominium unit. The term "purchaser" may be used interchangeably with the term "buyer." 

(6) "Bylaws" means the bylaws of the association as they are amended from time to time. 

(7) "Committee" means a group of board members, unit owners, or board members and unit owners appointed by the board or a member of the board to make recommendations to the board regarding the proposed annual budget or to take action on behalf of the board. 

(8) "Common elements" means the portions of the condominium property not included in the units. 

(9) "Common expenses" means all expenses properly incurred by the association in the performance of its duties, including expenses specified in § 914. 

(10) "Common surplus" means the amount of all receipts or revenues, including assessments, rents, or profits, collected by a condominium association which exceeds common expenses. 

(11) "Condominium" means that form of ownership of real property created pursuant to this chapter, which is comprised entirely of units that may be owned by one or more persons, and in which there is, appurtenant to each unit, an undivided share in common elements. 

(12) "Condominium parcel" means a unit, together with the undivided share in the common elements appurtenant to the unit. 

(13) "Condominium property" means the lands, leaseholds, and personal property that are subjected to condominium ownership, whether or not contiguous, and all improvements thereon and all easements and rights appurtenant thereto intended for use in connection with the condominium. 

(14) "Conspicuous type" means bold type in capital letters no smaller than the largest type, exclusive of headings, on the page on which it appears and, in all cases, at least 10-point type. Where conspicuous type is required, it must be separated on all sides from other type and print. Conspicuous type may be used in a contract for purchase and sale of a unit, a lease of a unit for more than 5 years, or a prospectus or offering circular only where required by law. 

(15) "Declaration," "declaration of condominium," or "declaration of a horizontal property regime (HPR)" means the instrument or instruments by which a condominium is created, as they are from time to time amended. 

(16) "Developer" means a person who creates a condominium or offers condominium parcels for sale or lease in the ordinary course of business, but does not include an owner or lessee of a condominium or cooperative unit who has acquired the unit for his or her own occupancy, nor does it include a cooperative association which creates a condominium by conversion of an existing residential cooperative after control of the association has been transferred to the unit owners if, following the conversion, the unit owners will be the same persons who were unit owners of the cooperative and no units are offered for sale or lease to the public as part of the plan of conversion. 

(17) "Developer control period" means the period during which the developer has the right to appoint a majority of the board members. The developer control period ends when a majority of the unit owners other than the developer elect a majority of the members of the board of an association in accordance with subsection (4) of § 940 below. 

(18) "Bureau" means the Bureau of Commercial Development. 

(19) "Land" means the surface of a legally described parcel of real property and includes, unless otherwise specified in the declaration and whether separate from or including such surface, airspace lying above and subterranean space lying below such surface. However, if so defined in the declaration, the term "land" may mean all or any portion of the airspace or subterranean space between two legally identifiable elevations and may exclude the surface of a parcel of real property and may mean any combination of the foregoing, whether or not contiguous. 

(20) "Limited common elements" means those common elements which are reserved for the use of a certain unit or units to the exclusion of all other units, as specified in the declaration. 

(21) "Multicondominium" means a real estate development containing two or more condominiums, all of which are operated by the same association. 

(22) "Operation" or "operation of the condominium" includes the administration and management of the condominium property. 

(23) "Rental agreement" means any written agreement, or oral agreement if for less duration than one year, providing for use and occupancy of premises. 

(24) "Residential condominium" means a condominium consisting of two or more units, any of which are intended for use as a private temporary or permanent residence, except that a condominium is not a residential condominium if the use for which the units are intended is primarily commercial or industrial and not more than three units are intended to be used for private residence, and are intended to be used as housing for maintenance, managerial, janitorial, or other operational staff of the condominium. A residential unit includes a unit intended as a private temporary or permanent residence as well as a unit not intended for commercial or industrial use. If a condominium is a residential condominium but contains units intended to be used for commercial or industrial purposes, then, with respect to those units which are not intended for or used as private residences, the condominium is not a residential condominium. A condominium which contains both commercial and residential units is a mixed-use condominium and is subject to the requirements of § 954 below. A hotel unit or a unit for transient occupancy (intended to be occupied for not more than 28 days) shall be considered to be for commercial use and not residential use. A project containing these units as well as residential units shall be a mixed use condominium for the purposes of this Act. 

(25) "Special assessment" means any assessment levied against a unit owner other than the assessment required by a budget adopted annually. 

(26) "Unit" means a part of the condominium property which is subject to exclusive ownership. A unit may be in improvements, land, or land and improvements together, as specified in the declaration. 

(27) "Unit owner" or "owner of a unit" means a record owner of legal title to a condominium parcel. 

(28) "Voting certificate" means a document which designates one of the record title owners, or the corporate, partnership, or entity representative, who is authorized to vote on behalf of a condominium unit that is owned by more than one owner or by any entity. 

(29) "Voting interests" means the voting rights distributed to the association members pursuant to this chapter. In a multicondominium association, the voting interests of the association are the voting rights distributed to the unit owners in all condominiums operated by the association. On matters related to a specific condominium in a multicondominium association, the voting interests of the condominium are the voting rights distributed to the unit owners in that condominium. 

§ 902. Power of attorney; compliance with chapter. The use of a power of attorney that affects any aspect of the operation of a condominium shall be subject to and in compliance with the provisions of this chapter and all condominium documents, association rules and other rules adopted pursuant to this chapter, and all other covenants, conditions, and restrictions in force at the time of the execution of the power of attorney. 

§ 903. Creation of condominiums; contents of declaration. Every condominium created in the Republic of Palau shall be created pursuant to this chapter. 

(1) A condominium may be created on land owned in fee simple or held under a lease complying with the provisions of § 950 below and 39 PNC § 302. 

(2) A condominium is created by recording a declaration in the public records where the land is located, executed and acknowledged with the requirements for a deed. All persons who have record title to the interest in the land being submitted to condominium ownership, or their lawfully authorized agents, must join in the execution of the declaration. Upon the recording of the declaration, or an amendment adding a phase to the condominium under § 953(6) below, all units described in the declaration or phase amendment as being located in or on the land then being submitted to condominium ownership shall come into existence, regardless of the state of completion of planned improvements in which the units may be located. Upon recording the declaration of condominium pursuant to this section, the developer shall file the recording information with the Bureau within 120 calendar days on a form prescribed by the Bureau. 

(3) All persons who have any record interest in any mortgage encumbering the interest in the land being submitted to condominium ownership must either join in the execution of the declaration or execute, with the requirements for deed, and record, a consent to the declaration or an agreement subordinating their mortgage interest to the declaration. 

(4) The declaration must contain or provide for the following matters: 

(a) A statement submitting the property to condominium ownership. 

(b) The name by which the condominium property is to be identified, which shall include the word "condominium" or be followed by the words "a condominium." 

(c) The legal description of the land and, if a leasehold estate is submitted to condominium, an identification of the lease. 

(d) An identification of each unit by letter, name, or number, or combination thereof, so that no unit bears the same designation as any other unit. 

(e) A survey of the land which meets the minimum technical standards established by the Division of Lands and Surveys, and a graphic description of the improvements in which units are located and a plot plan thereof that, together with the declaration, are in sufficient detail to identify the common elements and each unit and their relative locations and approximate dimensions. Failure of the survey to meet minimum technical standards shall not invalidate an otherwise validly created condominium. The survey, graphic description, and plot plan may be in the form of exhibits consisting of building plans, floor plans, maps, surveys, or sketches. If the construction of the condominium is not substantially completed, there shall be a statement to that effect, and, upon substantial completion of construction, the developer or the association shall amend the declaration to include the certificate described below. The amendment may be accomplished by referring to the recording data of a survey of the condominium that complies with the certificate. A certificate of a surveyor and mapper licensed or authorized to practice in the Republic of Palau shall be included in or attached to the declaration or the survey or graphic description as recorded under § 904 below that the construction of the improvements is substantially complete so that the material, together with the provisions of the declaration describing the condominium property, is an accurate representation of the location and dimensions of the improvements and so that the identification, location, and dimensions of the common elements and of each unit can be determined from these materials. Completed units within each substantially completed building in a condominium development may be conveyed to purchasers, notwithstanding that other buildings in the condominium are not substantially completed, provided that all planned improvements, including, but not limited to, landscaping, utility services and access to the unit, and common-element facilities serving such building, as set forth in the declaration, are first completed and the declaration of condominium is first recorded and provided that as to the units being conveyed there is a certificate of a surveyor and mapper as required above, including certification that all planned improvements, including, but not limited to, landscaping, utility services and access to the unit, and common-element facilities serving the building in which the units to be conveyed are located have been substantially completed, and such certificate is recorded with the original declaration or as an amendment to such declaration. This section shall not, however, operate to require development of improvements and amenities declared to be included in future phases pursuant to § 953 below prior to conveying a unit as provided herein. For the purposes of this section, a "certificate of a surveyor and mapper" means certification by a surveyor and mapper in the form provided herein and may include, along with certification by a surveyor and mapper, when appropriate, certification by an architect or engineer authorized to practice in the Republic of Palau. Notwithstanding the requirements of substantial completion provided in this section, nothing contained herein shall prohibit or impair the validity of a mortgage encumbering units together with an undivided interest in the common elements as described in a declaration of condominium recorded prior to the recording of a certificate of a surveyor and mapper as provided herein. 

(f) The undivided share of ownership of the common elements and common surplus of the condominium that is appurtenant to each unit stated as a percentage or a fraction of the whole. In the declaration of condominium for residential condominiums, the ownership share of the common elements assigned to each residential unit shall be either an equal, undivided share of the common elements or based upon the total square footage of each residential unit in uniform relationship to the total square footage of each other residential unit in the condominium. 

(g) The percentage or fractional shares of liability for common expenses of the condominium, which, for all residential units, must be the same as the undivided shares of ownership of the common elements and common surplus appurtenant to each unit as provided for in paragraph (f). 

(h) If a developer reserves the right, in a declaration recorded after the effective date of the Act, to create a multicondominium, the declaration must state, or provide a specific formula for determining, the fractional or percentage shares of liability for the common expenses of the association and of ownership of the common surplus of the association to be allocated to the units in each condominium to be operated by the association. If the declaration as originally recorded fails to so provide, the share of liability for the common expenses of the association and of ownership of the common surplus of the association allocated to each unit in each condominium operated by the association shall be a fraction of the whole, the numerator of which is the number "one" and the denominator of which is the total number of units in all condominiums operated by the association. 

(I) The name of the association, which must be a corporation for profit. 

(j) Unit owners' membership and voting rights in the association. 

(k) The document or documents creating the association, which may be attached as an exhibit. 

(l) A copy of the bylaws, which shall be attached as an exhibit. Defects or omissions in the bylaws shall not affect the validity of the condominium or title to the condominium parcels.

(m) Other desired provisions not inconsistent with this chapter. 

(n) The creation of a nonexclusive easement for ingress and egress over streets, walks, and other rights-of-way serving the units of a condominium, as part of the common elements necessary to provide reasonable access to the public ways, or a dedication of the streets, walks, and other rights-of-way to the public. All easements for ingress and egress shall not be encumbered by any leasehold or lien other than those on the condominium parcels, unless: 

1. Any such lien is subordinate to the rights of unit owners, or 

2. The holder of any encumbrance or leasehold of any easement has executed and recorded an agreement that the use-rights of each unit owner will not be terminated as long as the unit owner has not been evicted because of a default under the encumbrance or lease, and the use-rights of any mortgagee of a unit who has acquired title to a unit may not be terminated. 

(5) The declaration may include covenants and restrictions concerning the use, occupancy, and transfer of the units permitted by law with reference to real property. However, the rule against perpetuities shall not defeat a right given any person or entity by the declaration for the purpose of allowing unit owners to retain reasonable control over the use, occupancy, and transfer of units. 

(6) A person who joins in, or consents to the execution of, a declaration subjects his or her interest in the condominium property to the provisions of the declaration. 

(7) All provisions of the declaration are enforceable equitable servitudes, run with the land, and are effective until the condominium is terminated. 

§ 904. Recording of declaration. 
(1)	(a) When executed as required by § 903 above and upon payment of such fees, if any, as the President may fix, a declaration together with all exhibits and all amendments is entitled to recordation by the Clerk of Courts as an agreement relating to the conveyance of land. 

(b) The Clerk of Courts shall maintain an index or indexes in which: 

(I) the record of each declaration contains a reference to the record of each transfer of land, maintained pursuant to 39 PNC § 401, that is affected by the declaration;

(ii) the record of each transfer of a unit contains a reference to the declaration of the condominium of which the unit is a part; and 

(iii) the record of each transfer of land affected by a declaration, maintained pursuant to 39 PNC § 401, contains a reference to the declaration that affects that land. 

(2) In addition to the declaration, the developer shall provide the Clerk of Courts a certification from the state and national government that the proposed condominium project complies with all relevant environmental, zoning, and other land use laws and regulations. These certifications shall be recorded with the declaration. 

(3) Graphic descriptions of improvements constituting exhibits to a declaration, when accompanied by the certificate of a surveyor required by § 903 above, may be recorded as a part of a declaration without approval of any public body or officer. 

(4) The Clerk of Courts recording the declaration may, for his or her convenience, file the exhibits of a declaration which contains graphic descriptions of improvements in a separate book, and shall indicate the place of filing upon the margin of the record of the declaration. 

(5) 	(a) If the declaration does not have the certificate or the survey or graphic description of the improvements required under § 903(4)(e) above, the developer shall deliver therewith to the Clerk an estimate, signed by a surveyor authorized to practice in the Republic of Palau, of the cost of a final survey or graphic description providing the certificate prescribed by § 903(4)(e)above, and shall deposit with the Clerk the sum of money specified in the estimate. The final survey or graphic description required under § 903(4)(e) above shall be finalized prior to the final creation of the condominium under § 903(2) above. 

(b) The Clerk shall hold the money until an amendment to the declaration is recorded that complies with the certificate requirements of § 903(4)(e). At that time, the Clerk shall pay to the person presenting the amendment to the declaration the sum of money deposited, without making any charge for holding the sum, receiving it, or paying out, other than the fees required for recording the condominium documents. 

(c) If the sum of money held by the Clerk has not been paid to the developer or association as provided in paragraph (b) by three years after the date the declaration was originally recorded, the Clerk in his or her discretion may notify, in writing, the registered agent of the association that the sum is still available and the purpose for which it was deposited. If the association does not record the certificate within 90 days after the Clerk has given the notice, the Clerk may disburse the money to the developer. If the developer cannot be located, the Clerk shall disburse the money to the Bureau. 

(6) When a declaration of condominium is recorded pursuant to this section, a certificate or receipted bill shall be filed with the Clerk of Court showing that all taxes due and owing on the property have been paid in full as of the date of recordation. 

§ 905. Condominium parcels; appurtenances; possession and enjoyment. 
(1) A condominium parcel created by the declaration is a separate parcel of real property, even though the condominium is created on a leasehold. 

(2) There shall pass with a unit, as appurtenances thereto: 

(a) An undivided share in the common elements and common surplus appurtenant to the unit as provided in the declaration. 

(b) The exclusive right to use such portion of the common elements as may be provided by the declaration, including the right to transfer such right to other units or unit owners to the extent authorized by the declaration as originally recorded. 

(c) An exclusive easement for the use of the airspace occupied by the unit as it exists at any particular time and as the unit may lawfully be altered or reconstructed from time to time. An easement in airspace which is vacated shall be terminated automatically, but may be temporarily reinstated in order to perform permitted alteration or reconstruction to the unit. 

(d) Membership in the association designated in the declaration, with the full voting rights appertaining to the association. 

(e) Other appurtenances as may be provided in the declaration. 

(3) A unit owner is entitled to the exclusive possession of his or her unit, subject to the provisions of § 909(5) below. He or she is entitled to use the common elements in accordance with the purposes for which they are intended, but no use may hinder or encroach upon the lawful rights of other unit owners. 

(4) When a unit is leased, a tenant shall have all use rights in the association property and those common elements otherwise readily available for use generally by unit owners and the unit owner shall not have such rights except as a guest, unless such rights are waived in writing by the tenant. Nothing in this subsection shall interfere with the access rights of the unit owner as a landlord pursuant to any agreement or applicable law. The association shall have the right to adopt rules to prohibit dual usage by a unit owner and a tenant of association property and common elements otherwise readily available for use generally by unit owners. 

§ 905A. Restraint upon separation and partition of common elements. 
(1) The undivided share in the common elements which is appurtenant to a unit shall not be separated from it and shall pass with the title to the unit, whether or not separately described. 

(2) The share in the common elements appurtenant to a unit cannot be conveyed or encumbered except together with the unit. 

(3) The shares in the common elements appurtenant to units are undivided, and no action for partition of the common elements shall lie. 

§ 906. Common elements. 
(1) "Common elements" includes: 

(a) The condominium property which is not included within the units. 

(b) Easements through units for conduits, ducts, plumbing, wiring, and other facilities for the furnishing of utility services to units and the common elements. 

(c) An easement of support in every portion of a unit which contributes to the support of a building. 

(d) The property and installations required for the furnishing of utilities and other services to more than one unit or to the common elements. 

(2) The declaration may designate other parts of the condominium property as common elements. 

§ 907. Legal description of condominium parcels. Following the recording of the declaration, a description of a condominium parcel by the number or other designation by which the unit is identified in the declaration, together with the recording data identifying the declaration, shall be a sufficient legal description for all purposes. The description includes all appurtenances to the unit concerned, whether or not separately described, including, but not limited to, the undivided share in the common elements appurtenant to the unit. 

§ 908. Amendment of declaration; correction of error or omission in declaration by the court. 
(1) 	(a) If the declaration fails to provide a method of amendment, the declaration may be amended as to all matters except those described in subsection (4) or subsection (8) if the amendment is approved by the owners of not less than two-thirds of the units. Except as to those matters described in subsection (4) or subsection (8), no declaration shall require that amendments be approved by more than four-fifths of the voting interests. 

(b) Nonmaterial errors or omissions in the amendment process will not invalidate an otherwise properly promulgated amendment. 

(2) An amendment, other than amendments made by the developer pursuant to § 903, § 953, and § 963(6), (7), and (9) of this Chapter without a vote of the unit owners and any rights the developer may have in the declaration to amend without consent of the unit owners which shall be limited to matters other than those under subsections (4) and (8), shall be evidenced by a certificate of the association which shall include the recording data identifying the declaration and shall be executed in the form required for the execution of a deed. An amendment by the developer must be evidenced in writing, but a certificate of the association is not required. 

(3) An amendment of a declaration is effective when properly recorded in the public records where the declaration is recorded. 

(4) Unless otherwise provided in the declaration as originally recorded, or as amended with the consent of the owner of the unit, whether or not that owner is the developer, no amendment may change the configuration or size of any unit in any material fashion, materially alter or modify the appurtenances to the unit, or change the proportion or percentage by which the unit owner shares the common expenses of the condominium and owns the common surplus of the condominium unless the record owner of the unit and all record owners of liens on the unit join in the execution of the amendment and unless all the record owners of all other units in the same condominium approve the amendment. The acquisition of property by the association, and material alterations or substantial additions to such property or the common elements by the association in accordance with § 909(7) or § 912 below, shall not be deemed to constitute a material alteration or modification of the appurtenances to the units. A declaration may not require the approval of less than a majority of total voting interests of the condominium for amendments under this subsection, unless otherwise required by a governmental entity. However, the majority voting requirement of this subsection does not impinge on the developer's right to unilaterally alter one or more units if the developer has previously reserved that right and has, in advance of the alteration, disclosed that right to the unit owners. 

(5) If it appears that through a scrivener's error a unit has not been designated as owning an appropriate undivided share of the common elements or does not bear an appropriate share of the common expenses or that all the common expenses or interest in the common surplus or all of the common elements in the condominium have not been distributed in the declaration, so that the sum total of the shares of common elements which have been distributed or the sum total of the shares of the common expenses or ownership of common surplus fails to equal 100 percent, or if it appears that more than 100 percent of common elements or common expenses or ownership of the common surplus have been distributed, the error may be corrected by filing an amendment to the declaration approved by the board of administration, a majority of the unit owners, or by the developer if that right is reserved in the declaration. 

(6) The common elements designated by the declaration may be enlarged by an amendment to the declaration. The amendment must describe the interest in the property and must submit the property to the terms of the declaration. The amendment must be approved and executed as provided in this section. The amendment divests the association of title to the land and vests title in the unit owners as part of the common elements, without naming them and without further conveyance, in the same proportion as the undivided shares in the common elements that are appurtenant to the unit owned by them. 

(7) The declarations, bylaws, and common elements of two or more independent condominiums of a single complex may be merged to form a single condominium, upon the approval of such voting interest of each condominium as is required by the declaration for modifying the appurtenances to the units or changing the proportion or percentages by which the owners of the parcel share the common expenses and own the common surplus; upon the approval of all record owners of liens; and upon the recording of new or amended articles of incorporation, declarations, and bylaws. 

(8) If there is an omission or error in a declaration, or in any other document required by law to establish the condominium, the association may correct the error or omission by an amendment to the declaration or to the other document required to create a condominium in the manner provided in the declaration to amend the declaration or, if none is provided, by vote of a majority of the voting interests of the condominium. The amendment is effective when passed and approved and a certificate of amendment is executed and recorded as provided in subsections (2) and (3). This procedure for amendment cannot be used if such an amendment would materially or adversely affect property rights of unit owners, unless the affected unit owners consent in writing. This subsection does not restrict the powers of the association to otherwise amend the declaration, or other documentation, but authorizes a simple process of amendment requiring a lesser vote for the purpose of curing defects, errors, or omissions when the property rights of unit owners are not materially or adversely affected. 

(9) If there is an omission or error in a declaration of condominium, or any other document required to establish the condominium, which omission or error would affect the valid existence of the condominium, the Supreme Court has jurisdiction to entertain a petition of one or more of the unit owners in the condominium, or of the association, to correct the error or omission, and the action may be a class action. The court may require that one or more methods of correcting the error or omission be submitted to the unit owners to determine the most acceptable correction. All unit owners, the association, and the mortgagees of a first mortgage of record must be joined as parties to the action. Service of process on unit owners may be by publication, but the plaintiff must furnish every unit owner not personally served with process with a copy of the petition and final decree of the court by certified mail, return receipt requested, at the unit owner's last known residence address. If an action to determine whether the declaration or another condominium document complies with the mandatory requirements for the formation of a condominium is not brought within three years of the recording of the declaration, the declaration and other documents shall be effective under this chapter to create a condominium, as of the date the declaration was recorded, whether or not the documents substantially comply with the mandatory requirements of law. However, both before and after the expiration of this three-year period, the Supreme Court has jurisdiction to entertain a petition permitted under this subsection for the correction of the documentation, and other methods of amendment may be utilized to correct the errors or omissions at any time. 

(10) Notwithstanding any provision to the contrary contained in this section, a declaration may not require the consent or joinder of some or all mortgagees of units to or in amendments to the declaration, unless the requirement is limited to amendments materially affecting the rights or interests of the mortgagees, and unless the requirement provides that such consent may not be unreasonably withheld. It shall be presumed that, except as to those matters described in subsections (4) and (8), amendments to the declaration do not materially affect the rights or interests of mortgagees. In the event mortgagee consent is provided other than by properly recorded joinder, such consent shall be evidenced by affidavit of the association recorded in the public records where the declaration is recorded. 

(11)	 (a) With respect to an existing multicondominium association, any amendment to change the fractional or percentage share of liability for the common expenses of the association and ownership of the common surplus of the association must be approved by at least a majority of the total voting interests of each condominium operated by the association unless the declarations of all condominiums operated by the association uniformly require approval by a greater percentage of the voting interests of each condominium. 

(b) Unless approval by a greater percentage of the voting interests of an existing multicondominium association is expressly required in the declaration of an existing condominium, the declaration may be amended upon approval of at least a majority of the total voting interests of each condominium operated by the multicondominium association for the purpose of: 

1. Setting forth in the declaration the formula currently utilized, but not previously stated in the declaration, for determining the percentage or fractional shares of liability for the common expenses of the multicondominium association and ownership of the common surplus of the multicondominium association. 

2. Providing for the creation or enlargement of a multicondominium association by the merger or consolidation of two or more associations and changing the name of the association, as appropriate. 

§ 909. The Association. 
(1) CORPORATE ENTITY. 

(a) The operation of the condominium shall be by the association, which must be a Palau corporation for profit. The owners of units shall be shareholders or members of the association. The officers and directors of the association have a fiduciary relationship to the unit owners. It is the intent of the Legislature that nothing in this paragraph shall be construed as providing for or removing a requirement of a fiduciary relationship between any manager employed by the association and the unit owners. An officer, director, or manager may not solicit, offer to accept, or accept any thing or service of value for which consideration has not been provided for his or her own benefit or that of his or her immediate family, from any person providing or proposing to provide goods or services to the association. Any such officer, director, or manager who knowingly so solicits, offers to accept, or accepts any thing or service of value is subject to a civil penalty pursuant to § 960(1)(d) below. However, this paragraph does not prohibit an officer, director, or manager from accepting services or items received in connection with trade fairs or education programs. An association may operate more than one condominium. 

(b) A director of the association who is present at a meeting of its board at which action on any corporate matter is taken shall be presumed to have assented to the action taken unless he or she votes against such action or abstains from voting in respect thereto because of an asserted conflict of interest. Directors may not vote by proxy or by secret ballot at board meetings, except that officers may be elected by secret ballot. A vote or abstention for each member present shall be recorded in the minutes. 

(c) A unit owner does not have any authority to act for the association by reason of being a unit owner. 

(2) POWERS AND DUTIES. The powers and duties of the association include those set forth in this section and, except as expressly limited or restricted in this chapter, those set forth in the code and regulations governing Palau business associations. 

(3) POWER TO MANAGE CONDOMINIUM PROPERTY AND TO CONTRACT, SUE, AND BE SUED. The association may contract, sue, or be sued with respect to the exercise or nonexercise of its powers. For these purposes, the powers of the association include, but are not limited to, the maintenance, management, and operation of the condominium property. After control of the association is obtained by unit owners other than the developer, the association may institute, maintain, settle, or appeal actions or hearings in its name on behalf of all unit owners concerning matters of common interest to most or all unit owners, including, but not limited to, the common elements; the roof and structural components of a building or other improvements; mechanical, electrical, and plumbing elements serving an improvement or a building; representations of the developer pertaining to any existing or proposed commonly used facilities; and protesting ad valorem taxes on units and on the common elements; and may defend actions in eminent domain or bring inverse condemnation actions. If the association has the authority to maintain a class action, the association may be joined in an action as representative of that class with reference to litigation and disputes involving the matters for which the association could bring a class action. Nothing herein limits any statutory or common-law right of any individual unit owner or class of unit owners to bring any action without participation by the association which may otherwise be available. 

(4) ASSESSMENTS; MANAGEMENT OF COMMON ELEMENTS. The association has the power to make and collect assessments and to lease, maintain, repair, and replace the common elements; however, the association may not charge a use fee against a unit owner for the use of common elements or association property unless otherwise provided for in the declaration of condominium or by a majority vote of the association or unless the charges relate to expenses incurred by an owner having exclusive use of the common elements or association property. 

(5) RIGHT OF ACCESS TO UNITS. The association has the irrevocable right of access to each unit during reasonable hours, when necessary for the maintenance, repair, or replacement of any common elements or of any portion of a unit to be maintained by the association pursuant to the declaration or as necessary to prevent damage to the common elements or to a unit or units. This right of access by the association shall be subject to reasonable notice to the unit owner, except in the case of emergency. 

(6) TITLE TO PROPERTY. 
(a) The association has the power to acquire title to property or otherwise hold, convey, lease, and mortgage association property for the use and benefit of its members. The power to acquire personal property shall be exercised by the board of administration. Except as otherwise permitted in subsections (8) and (9) and in § 913 below, no association may acquire, convey, lease, or mortgage association real property except in the manner provided in the declaration, and if the declaration does not specify the procedure, then approval of 75 percent of the total voting interests shall be required. 

(b) Subject to the provisions of § 910(2)(k)below, the association, through its board, has the limited power to convey a portion of the common elements to a condemning authority for the purposes of providing utility easements, right-of-way expansion, or other public purposes, whether negotiated or as a result of eminent domain proceedings. 

[sic](8) PURCHASE OF LEASES. The association has the power to purchase any land or recreation lease upon the approval of such voting interest as is required by the declaration. If the declaration makes no provision for acquisition of the land or recreation lease, the vote required shall be that required to amend the declaration to permit the acquisition. 

(9) PURCHASE OF UNITS. The association has the power, unless prohibited by the declaration, articles of incorporation, or bylaws of the association, to purchase units in the condominium and to acquire and hold, lease, mortgage, and convey them. There shall be no limitation on the association's right to purchase a unit at a foreclosure sale resulting from the association's foreclosure of its lien for unpaid assessments, or to take title by deed in lieu of foreclosure. 

(10) EASEMENTS. Unless prohibited by the declaration, the board of administration has the authority, without the joinder of any unit owner, to grant, modify, or move any easement if the easement constitutes part of or crosses the common elements or association property. This subsection does not authorize the board of administration to modify, move, or vacate any easement created in whole or in part for the use or benefit of anyone other than the unit owners, or crossing the property of anyone other than the unit owners, without the consent or approval of those other persons having the use or benefit of the easement, as required by law or by the instrument creating the easement. Nothing in this subsection affects the minimum requirements of § 903(4)(m) or the powers enumerated in subsection (3). 

(11) INSURANCE. 
(a) A unit-owner controlled association shall use its best efforts to obtain and maintain adequate insurance to protect the association, the association property, the common elements, and the condominium property required to be insured by the association pursuant to paragraph (b). If the association is developer-controlled, the association shall exercise due diligence to obtain and maintain such insurance. Failure to obtain and maintain adequate insurance during any period of developer control shall constitute a breach of fiduciary responsibility by the developer-appointed members of the board of directors of the association, unless said members can show that despite such failure, they have exercised due diligence. An association may also obtain and maintain liability insurance for directors and officers, insurance for the benefit of association employees, and flood insurance for common elements, association property, and units. An association or group of associations may self insure against claims against the association, the association property, and the condominium property required to be insured by an association, in accordance with law. A copy of each policy of insurance in effect shall be made available for inspection by unit owners at reasonable times. 

(b) Every hazard policy which is issued to protect a condominium building shall provide that the word "building" wherever used in the policy include, but not necessarily be limited to, fixtures, installations, or additions comprising that part of the building within the unfinished interior surfaces of the perimeter walls, floors, and ceilings of the individual units initially installed, or replacements thereof of like kind or quality, in accordance with the original plans and specifications, or as they existed at the time the unit was initially conveyed if the original plans and specifications are not available. However, the word "building" does not include unit floor coverings, wall coverings, or ceiling coverings, and, does not include the following equipment if it is located within a unit and the unit owner is required to repair or replace such equipment: electrical fixtures, appliances, air conditioner or heating equipment, water heaters, or built-in cabinets. With respect to the coverage provided for by this paragraph, the unit owners shall be considered additional insurers under the policy. 

(c) Every insurance policy issued to an individual unit owner shall provide that the coverage afforded by such policy is excess over the amount recoverable under any other policy covering the same property without rights of subrogation against the association. 

(d) The association shall obtain and maintain adequate insurance or fidelity bonding of all persons who control or disburse funds of the association. The insurance policy or fidelity bond must cover the maximum funds that will be in the custody of the association or its management agent at any one time. As used in this paragraph, the term "persons who control or disburse funds of the association" includes, but is not limited to, those individuals authorized to sign checks and the president, secretary, and treasurer of the association. The association shall bear the cost of bonding. 

(12) OFFICIAL RECORDS. 
(a) From the inception of the association, the association shall maintain each of the following items, when applicable, which shall constitute the official records of the association: 

1. A copy of the plans, permits, warranties, and other items provided by the developer pursuant to § 940(4) below. 

2. A photocopy of the recorded declaration of condominium of each condominium operated by the association and of each amendment to each declaration. 

3. A photocopy of the recorded bylaws of the association and of each amendment to the bylaws. 

4. A certified copy of the articles of incorporation of the association, or other documents creating the association, and of each amendment thereto. 

5. A copy of the current rules of the association. 

6. A book or books which contain the minutes of all meetings of the association, of the board of directors, and of unit owners, which minutes shall be retained for a period of not less than seven years. 

7. A current roster of all unit owners and their mailing addresses, unit identifications, voting certifications, and, if known, telephone numbers. 

8. A current roster of unit owners residing outside the Republic of Palau, which shall include the names and contact information for the local agent appointed by the unit owner to receive notices, service of process, and other documents. 

9. All current insurance policies of the association and condominiums operated by the association. 

10. A current copy of any management agreement, lease, or other contract to which the association is a party or under which the association or the unit owners have an obligation or responsibility. 

11. Bills of sale or transfer for all property owned by the association. 

12. Accounting records for the association and separate accounting records for each condominium which the association operates. All accounting records shall be maintained for a period of not less than seven years. The accounting records shall include, but are not limited to: 

a. Accurate, itemized, and detailed records of all receipts and expenditures. 

b. A current account and a monthly, bimonthly, or quarterly statement of the account for each unit designating the name of the unit owner, the due date and amount of each assessment, the amount paid upon the account, and the balance due. 

c. All audits, reviews, accounting statements, and financial reports of the association or condominium. 

d. All contracts for work to be performed. Bids for work to be performed shall also be considered official records and shall be maintained for a period of one year. 

13. Ballots, sign-in sheets, voting proxies, and all other papers relating to voting by unit owners, which shall be maintained for a period of one year from the date of the election, vote, or meeting to which the document relates. 

14. All rental records, when the association is acting as agent for the rental of condominium units. 

15. A copy of the current question and answer sheet as described by § 963. 

16. All other records of the association not specifically included in the foregoing which are related to the operation of the association. 

(b) The official records of the association shall be maintained within the Republic of Palau. The records of the association shall be made available to a unit owner within 5 working days after receipt of written request by the board or its designee. This paragraph may be complied with by having a copy of the official records of the association available for inspection or copying on the condominium property or association property. 

(c) The official records of the association are open to inspection by any association member or the authorized representative of such member at all reasonable times. The right to inspect the records includes the right to make or obtain copies, at the reasonable expense, if any, of the association member. The association may adopt reasonable rules regarding the frequency, time, location, notice, and manner of record inspections and copying. The failure of an association to provide the records within 10 working days after receipt of a written request shall create a rebuttable presumption that the association willfully failed to comply with this paragraph. A unit owner who is denied access to official records is entitled to the actual damages or minimum damages for the association's willful failure to comply with this paragraph. The minimum damages shall be $50 per calendar day up to 10 days, the calculation to begin on the 11th working day after receipt of the written request. The failure to permit inspection of the association records as provided herein entitles any person prevailing in an enforcement action to recover reasonable attorney's fees from the person in control of the records who, directly or indirectly, knowingly denied access to the records for inspection. The association shall maintain an adequate number of copies of the declaration, articles of incorporation, bylaws, and rules, and all amendments to each of the foregoing, as well as the question and answer sheet provided for in § 963 and year-end financial information required in this section on the condominium property to ensure their availability to unit owners and prospective purchasers, and may charge its actual costs for preparing and furnishing these documents to those requesting the same. Notwithstanding the provisions of this paragraph, the following records shall not be accessible to unit owners: 

1. Any record protected by the lawyer-client privilege; and any record protected by the work-product privilege, including any record prepared by an association attorney or prepared at the attorney's express direction; which reflects a mental impression, conclusion, litigation strategy, or legal theory of the attorney or the association, and which was prepared exclusively for civil or criminal litigation or for adversarial administrative proceedings, or which was prepared in anticipation of imminent civil or criminal litigation or imminent adversarial administrative proceedings until the conclusion of the litigation or adversarial administrative proceedings. 

2. Information obtained by an association in connection with the approval of the lease, sale, or other transfer of a unit. 

3. Medical records of unit owners. 

(d) The association shall prepare a question and answer sheet as described in § 963 below, and shall update it annually. 

(13) FINANCIAL REPORTING. Within 90 days after the end of the fiscal year, or annually on a date provided in the bylaws, the association shall prepare and complete, or cause to be prepared and completed by a third party, a financial report for the preceding fiscal year. Within 21 days after the financial report is completed or received by the association from the third party, the association shall mail to each unit owner at the address last furnished to the association by the unit owner, or hand deliver to each unit owner, a copy of the financial report or a notice that a copy of the financial report will be mailed, emailed, faxed, or hand delivered to the unit owner, without charge, upon receipt of a written request from the unit owner. The Bureau shall adopt rules setting forth uniform accounting principles and standards to be used by all associations and shall adopt rules addressing financial reporting requirements for multicondominium associations. In adopting such rates, the Bureau shall consider the number of members and annual revenues of an association. The Bureau shall adopt rules governing the financial reporting of condominium associations, including: 

(a) The financial reports or other financial information condominium associations shall produce or cause to be produced, based on the annual revenues. 

(b) The financial reports or other compiled financial information an association may prepare or cause to be prepared, without a meeting of or approval by the unit owners. 

(c) The financial reports or other compiled financial information an association may prepare or cause to be prepared, if approved by a majority of the voting interests present at a properly called meeting of the association. 

Such meeting and approval must occur prior to the end of the fiscal year and is effective only for the fiscal year in which the vote is taken. With respect to an association to which the developer has not turned over control of the association, all unit owners, including the developer, may vote on issues related to the preparation of financial reports for the first two fiscal years of the association's operation, beginning with the fiscal year in which the declaration is recorded. Thereafter, all unit owners except the developer may vote on such issues until control is turned over to the association by the developer. 

(14) COMMINGLING. All funds collected by an association shall be maintained separately in the association's name. For investment purposes only, reserve funds may be commingled with operating funds of the association. Commingled operating and reserve funds shall be accounted for separately, and a commingled account shall not, at any time, be less than the amount identified as reserve funds. This subsection does not prohibit a multicondominium association from commingling the operating funds of separate condominiums or the reserve funds of separate condominiums. Furthermore, for investment purposes only, a multicondominium association may commingle the operating funds of separate condominiums with the reserve funds of separate condominiums. A manager or business entity, or an agent, employee, officer, or director of an association, shall not commingle any association funds with his or her funds or with the funds of any other condominium association or the funds of a community association. 

§ 910. Bylaws. 
(1) GENERALLY. 

(a) The operation of the association shall be governed by the articles of incorporation if the association is incorporated, and the bylaws of the association, which shall be included as exhibits to the recorded declaration. If one association operates more than one condominium, it shall not be necessary to rerecord the same articles of incorporation and bylaws as exhibits to each declaration after the first, provided that in each case where the articles and bylaws are not so recorded, the declaration expressly incorporates them by reference as exhibits and identifies the book and page of the public records where the first declaration to which they were attached is recorded. 

(b) No amendment to the articles of incorporation or bylaws is valid unless recorded with identification on the first page thereof of the book and page of the public records where the declaration of each condominium operated by the association is recorded. 

(2) REQUIRED PROVISIONS. 
The Bureau shall adopt rules governing the required provisions within all associations' bylaws. These provisions shall address the following: 

(a) Administration of the association, including the titles, duties, and powers of officers. Rules adopted under this subdivision shall provide for the hiring or retention of a property manager who is a resident of the Republic of Palau.

(b) Quorum and voting requirements for association meetings, as well as rules for voting by proxy. 

(c) Board of Administration meetings. 

(d) Unit owner meetings. 

(e) Budget meetings. 

(f) Structure and content of associations' annual budget. 

(g) Assessments of the unit owners by the board of administration. 

(h) Amendment of the bylaws. 

(I) Transfer fees assessed against a unit owner in connection with the sale, lease, sublease, or other transfer of a unit. 

(j) Recall of Board members. 

(k) The association's power to convey common elements of a condominium. The association's authority to convey these elements shall be limited to the conveyance to a condemning authority for the purpose of providing utility easements, right-of-way expansion, or other public purposes, whether negotiated or as the result of eminent domain proceedings. 

(3) OPTIONAL PROVISIONS.--The bylaws may provide for the following: 

(a) A method of adopting and amending administrative rules and regulations governing the details of the operation and use of the common elements. 

(b) Restrictions on and requirements for the use, maintenance, and appearance of the units and the use of the common elements. 

(c) Other provisions which are not inconsistent with this chapter or with the declaration, as may be desired. 

§ 911. Failure to fill vacancies on board of administration sufficient to constitute a quorum;:appointment of receiver upon petition of unit owner. If an association fails to fill vacancies on the board of administration sufficient to constitute a quorum in accordance with the bylaws, any unit owner may apply to the circuit court within whose jurisdiction the condominium lies for the appointment of a receiver to manage the affairs of the association. At least 30 days prior to applying to the circuit court, the unit owner shall mail to the association and post in a conspicuous place on the condominium property a notice describing the intended action, giving the association the opportunity to fill the vacancies. If during such time the association fails to fill the vacancies, the unit owner may proceed with the petition. If a receiver is appointed, the association shall be responsible for the salary of the receiver, court costs, and attorney's fees. The receiver shall have all powers and duties of a duly constituted board of administration and shall serve until the association fills vacancies on the board sufficient to constitute a quorum. 

§ 912. Maintenance; limitation upon. 
(1) Maintenance of the common elements is the responsibility of the association. The declaration may provide that certain limited common elements shall be maintained by those entitled to use the limited common elements or that the association shall provide the maintenance, either as a common expense or with the cost shared only by those entitled to use the limited common elements. If the maintenance is to be by the association at the expense of only those entitled to use the limited common elements, the declaration shall describe in detail the method of apportioning such costs among those entitled to use the limited common elements, and the association may use the provisions of § 915 below to enforce payment of the shares of such costs by the unit owners entitled to use the limited common elements. 

(2) 	(a) Except as otherwise provided in this section, there shall be no material alteration or substantial additions to the common elements or to real property which is association property, except in a manner provided in the declaration. If the declaration does not specify the procedure for approval of material alterations or substantial additions, 67 percent of the total voting interests of the association must approve the alterations or additions. 

(b) There shall not be any material alteration of, or substantial addition to, the common elements of any condominium operated by a multicondominium association unless approved in the manner provided in the declaration of the affected condominium or condominiums. If a declaration does not specify a procedure for approving such an alteration or addition, the approval of 67 percent of the total voting interests of each affected condominium is required. This subsection does not prohibit a provision in any declaration, 
 
articles of incorporation, or bylaws requiring the approval of unit owners in any condominium operated by the same association or requiring board approval before a material alteration or substantial addition to the common elements is permitted. 

(c) There shall not be any material alteration or substantial addition made to association real property operated by a multicondominium association, except as provided in the declaration, articles of incorporation, or bylaws. If the declaration, articles of incorporation, or bylaws do not specify the procedure for approving an alteration or addition to association real property, the approval of 67 percent of the total voting interests of the association is required. 

(3) A unit owner shall not do anything within his or her unit or on the common elements which would adversely affect the safety or soundness of the common elements or any portion of the association property or condominium property which is to be maintained by the association. 

§ 913. Association powers. An association has the power to enter into agreements to acquire leaseholds, memberships, and other possessory or use interests in lands or facilities such as country clubs, golf courses, marinas, and other recreational facilities. It has this power whether or not the lands or facilities are contiguous to the lands of the condominium, if they are intended to provide enjoyment, recreation, or other use or benefit to the unit owners. All of these leaseholds, memberships, and other possessory or use interests existing or created at the time of recording the declaration must be stated and fully described in the declaration. Subsequent to the recording of the declaration, the association may not acquire or enter into agreements acquiring these leaseholds, memberships, or other possessory or use interests except as authorized by the declaration. The declaration may provide that the rental, membership fees, operations, replacements, and other expenses are common expenses and may impose covenants and restrictions concerning their use and may contain other provisions not inconsistent with this chapter. 

§ 914. Common expenses and common surplus. 
(1) 	(a) Common expenses include the expenses of the operation, maintenance, repair, replacement, or protection of the common elements and association property, costs of carrying out the powers and duties of the association, and any other expense, whether or not included in the foregoing, designated as common expense by this chapter, the declaration, the documents creating the association, or the bylaws. Common expenses also include reasonable transportation services, insurance for directors and officers, road maintenance and operation expenses, in-house communications, and security services, which are reasonably related to the general benefit of the unit owners even if such expenses do not attach to the common elements or property of the condominium. However, such common expenses must either have been services or items provided on or after the date control of the association is transferred from the developer to the unit owners or must be services or items provided for in the condominium documents or bylaws. 

(b) The common expenses of a condominium within a multicondominium are the common expenses directly attributable to the operation of that condominium. The common expenses of a multicondominium association do not include the common expenses directly attributable to the operation of any specific condominium or condominiums within the multicondominium. 

(c) The common expenses of a multicondominium association may include categories of expenses related to the property or common elements within a specific condominium in the multicondominium if such property or common elements are areas in which all members of the multicondominium association have use rights or from which all members receive tangible economic benefits. Such common expenses of the association shall be identified in the declaration or bylaws of each condominium within the multicondominium association. 

(d) If so provided in the declaration, the cost of a master antenna television system or duly franchised cable television service obtained pursuant to a bulk contract shall be deemed a common expense. If the declaration does not provide for the cost of a master antenna television system or duly franchised cable television service obtained under a bulk contract as a common expense, the board may enter into such a contract, and the cost of the service will be a common expense but allocated on a per-unit basis rather than a percentage basis if the declaration provides for other than an equal sharing of common expenses, and any contract in which the cost of the service is not equally divided among all unit owners, may be changed by vote of a majority of the voting interests present at a regular or special meeting of the association, to allocate the cost equally among all units. The contract shall be for a term of not less than two years. 

1. Any contract made by the board for a community antenna system or duly franchised cable television service may be canceled by a majority of the voting interests present at the next regular or special meeting of the association. Any member may make a motion to cancel said contract, but if no motion is made or if such motion fails to obtain the required majority at the next regular or special meeting, whichever is sooner, following the making of the contract, then such contract shall be deemed ratified for the term therein expressed. 

2. Any such contract shall provide, and shall be deemed to provide if not expressly set forth, that any hearing-impaired or legally blind unit owner who does not occupy the unit with a non-hearing-impaired or sighted person, may discontinue the service without incurring disconnect fees, penalties, or subsequent service charges, and, as to such units, the owners shall not be required to pay any common expenses charge related to such service. If less than all members of an association share the expenses of cable television, the expense shall be shared equally by all participating unit owners. The association may use the provisions of § 915 below to enforce payment of the shares of such costs by the unit owners receiving cable television. 

(e) If any unpaid share of common expenses or assessments is extinguished by foreclosure of a superior lien or by a deed in lieu of foreclosure thereof, the unpaid share of common expenses or assessments are common expenses collectible from all the unit owners in the condominium in which the unit is located. 

(2) Except as otherwise provided by this chapter, funds for payment of the common expenses of a condominium shall be collected by assessments against the units in that condominium in the proportions or percentages provided in that condominium's declaration. In a residential or mixed-use condominium, each unit's share of the common expenses of the condominium and common surplus of the condominium shall be the same as the unit's appurtenant ownership interest in the common elements. 

(3) Common surplus is owned by unit owners in the same shares as their ownership interest in the common elements. 

(4)	 (a) Funds for payment of the common expenses of a condominium within a multicondominium shall be collected as provided in subsection (2). Common expenses of a multicondominium association shall be funded by assessments against all unit owners in the association in the proportion or percentage set forth in the declaration as required by § 903(4)(h) below, as applicable. 

(b) In a multicondominium association, the total common surplus owned by a unit owner consists of that owner's share of the common surplus of the association plus that owner's share of the common surplus of the condominium in which the owner's unit is located, in the proportion or percentage set forth in the declaration as required by § 903(4)(h) below, as applicable. 

§ 915. Assessments; liability; lien and priority; interest; collection. 
(1) 	(a) A unit owner, regardless of how his or her title has been acquired, including by purchase at a foreclosure sale or by deed in lieu of foreclosure, is liable for all assessments which come due while he or she is the unit owner. Additionally, a unit owner is jointly and severally liable with the previous owner for all unpaid assessments that came due up to the time of transfer of title. This liability is without prejudice to any right the owner may have to recover from the previous owner the amounts paid by the owner. 

(b) The liability of a first mortgagee or its successor or assignees who acquire title to a unit by foreclosure or by deed in lieu of foreclosure for the unpaid assessments that became due prior to the mortgagee's acquisition of title is limited to the lesser of: 

1. The unit's unpaid common expenses and regular periodic assessments which accrued or came due during the six months immediately preceding the acquisition of title and for which payment in full has not been received by the association; or 

2. One percent of the original mortgage debt. The provisions of this paragraph apply only if the first mortgagee joined the association as a defendant in the foreclosure action. Joinder of the association is not required if, on the date the complaint is filed, the association was dissolved or did not maintain an office or agent for service of process at a location which was known to or reasonably discoverable by the mortgagee. 

(c) The person acquiring title shall pay the amount owed to the association within 30 days after transfer of title. Failure to pay the full amount when due shall entitle the association to record a claim of lien against the parcel and proceed in the same manner as provided in this section for the collection of unpaid assessments. 

(d) Notwithstanding the provisions of paragraph (b), a first mortgagee or its successor or assignees who acquire title to a condominium unit as a result of the foreclosure of the mortgage or by deed in lieu of foreclosure of the mortgage shall be exempt from liability for all unpaid assessments attributable to the parcel or chargeable to the previous owner which came due prior to acquisition of title. 

(f) The provisions of this subsection shall not be available in any case where the unpaid assessments sought to be recovered by the association are secured by a lien recorded prior to the recording of the mortgage. The association shall be a proper party to intervene in any foreclosure proceeding to seek equitable relief. 

(g) For purposes of this subsection, the term "successor or assignee" as used with respect to a first mortgagee includes only a subsequent holder of the first mortgage. 

(2) The liability for assessments may not be avoided by waiver of the use or enjoyment of any common element or by abandonment of the unit for which the assessments are made. 

(3) Assessments and installments on them which are not paid when due bear interest at the rate provided in the declaration, from the due date until paid. This rate may not exceed the rate allowed by law, and, if no rate is provided in the declaration, interest shall accrue at the rate of 18 percent per year. Also, if the declaration or bylaws so provide, the association may charge an administrative late fee in addition to such interest, in an amount not to exceed the greater of $25 or five percent of each installment of the assessment for each delinquent installment that the payment is late. Any payment received by an association shall be applied first to any interest accrued by the association, then to any administrative late fee, then to any costs and reasonable attorney's fees incurred in collection, and then to the delinquent assessment. The foregoing shall be applicable notwithstanding any restrictive endorsement, designation, or instruction placed on or accompanying a payment. A late fee shall not be subject to the provisions in § 944(3) below. 

(4) If the association is authorized by the declaration or bylaws to approve or disapprove a proposed lease of a unit, the grounds for disapproval may include, but are not limited to, a unit owner being delinquent in the payment of an assessment at the time approval is sought. 

(5) 	(a) The association has a lien on each condominium parcel to secure the payment of assessments. Except as otherwise provided in subsection (1) and as set forth below, the lien is effective from and shall relate back to the recording of the original declaration of condominium, or, in the case of lien on a parcel located in a phase condominium, the last to occur of the recording of the original declaration or amendment thereto creating the parcel. However, as to first mortgages of record, the lien is effective from and after recording of a claim of lien in the public records where the condominium parcel is located. Nothing in this subsection shall be construed to bestow upon any lien, mortgage, or certified judgment of record, including the lien for unpaid assessments created herein, a priority which, by law, the lien, mortgage, or judgment did not have before that date. 

(b) To be valid, a claim of lien must state the description of the condominium parcel, the name of the record owner, the name and address of the association, the amount due, and the due dates. It must be executed and acknowledged by an officer or authorized agent of the association. No such lien shall be effective longer than one year after the claim of lien was recorded unless, within that time, an action to enforce the lien is commenced. The one-year period shall automatically be extended for any length of time during which the association is prevented from filing a foreclosure action by an automatic stay resulting from a bankruptcy petition filed by the parcel owner or any other person claiming an interest in the parcel. The claim of lien shall secure all unpaid assessments which are due and which may accrue subsequent to the recording of the claim of lien and prior to the entry of a certificate of title, as well as interest and all reasonable costs and attorney's fees incurred by the association incident to the collection process. Upon payment in full, the person making the payment is entitled to a satisfaction of the lien. 

(c) By recording a notice, a unit owner or the unit owner's agent or attorney may require the association to enforce a recorded claim of lien against his or her condominium parcel. After notice of contest of lien has been recorded, the Clerk of Court shall mail a copy of the recorded notice to the association by certified mail, return receipt requested, at the address shown in the claim of lien or most recent amendment to it and shall certify to the service on the face of the notice. Service is complete upon depositing the mail with the post office. After service, the association has 90 days in which to file an action to enforce the lien; and, if the action is not filed within the 90-day period, the lien is void. This 90-day period may be extended by the court for good cause shown. 

(6)	 (a) The association may bring an action in its name to foreclose a lien for assessments in the manner a mortgage of real property is foreclosed and may also bring an action to recover a money judgment for the unpaid assessments without waiving any claim of lien. The association is entitled to recover its reasonable attorney's fees incurred in either a lien foreclosure action or an action to recover a money judgment for unpaid assessments. 

(b) No foreclosure judgment may be entered until at least 30 days after the association gives written notice to the unit owner of its intention to foreclose its lien to collect the unpaid assessments. If this notice is not given at least 30 days before the foreclosure action is filed, and if the unpaid assessments, including those coming due after the claim of lien is recorded, are paid before the entry of a final judgment of foreclosure, the association shall not recover attorneys fees or costs. The notice must be given by delivery of a copy of it to the unit owner or by certified or registered mail, return receipt requested, addressed to the unit owner at his or her last known address; and, upon such mailing, the notice shall be deemed to have been given, and the court shall proceed with the foreclosure action and may award attorney's fees and costs as permitted by law. The notice requirements of this subsection are satisfied if the unit owner records a notice of contest of lien as provided in subsection (5). The notice requirements of this subsection do not apply if an action to foreclose a mortgage on the condominium unit is pending before any court; if the rights of the association would be affected by such foreclosure; and if actual, constructive, or substitute service of process has been made on the unit owner. 

(c) If the unit owner remains in possession of the unit after a foreclosure judgment has been entered, the court, in its discretion, may require the unit owner to pay a reasonable rental for the unit. If the unit is rented or leased during the pendency of the foreclosure action, the association is entitled to the appointment of a receiver to collect the rent. The expenses of the receiver shall be paid by the party which does not prevail in the foreclosure action. 

(d) The association has the power to purchase the condominium parcel at the foreclosure sale and to hold, lease, mortgage, or convey it. 

(7) A first mortgagee acquiring title to a condominium parcel as a result of foreclosure, or a deed in lieu of foreclosure, may not, during the period of its ownership of such parcel, whether or not such parcel is unoccupied, be excused from the payment of some or all of the common expenses coming due during the period of such ownership. 

(8) Within 15 days after receiving a written request therefor from a unit owner purchaser, or mortgagee, the association shall provide a certificate signed by an officer or agent of the association stating all assessments and other moneys owed to the association by the unit owner with respect to the condominium parcel. Any person other than the owner who relies upon such certificate shall be protected thereby. Compliance with this subsection may be compelled by court action, and in any such action the prevailing party is entitled to recover reasonable attorney's fees. 

(9) 	(a) A unit owner may not be excused from payment of the unit owner's share of common expenses unless all other unit owners are likewise proportionately excused from payment, except as provided in subsection (1) and in the following cases: 

1. If authorized by the declaration, a developer who is offering units for sale may elect to be excused from payment of assessments against those unsold units for a stated period of time after the declaration is recorded. However, the developer must pay common expenses incurred during such period which exceed regular periodic assessments against other unit owners in the same condominium. The stated period must terminate no later than the first day of the fourth calendar month following the month in which the first closing occurs of a purchase contract for a unit in that condominium. If a developer-controlled association has maintained all insurance coverage required by § 909(11)(a) above, common expenses incurred during the stated period resulting from a natural disaster or an act of God occurring during the stated period, which are not covered by proceeds from insurance maintained by the association, may be assessed against all unit owners owning units on the date of such natural disaster or act of God, and their respective successors and assigns, including the developer with respect to units owned by the developer. In the event of such an assessment, all units shall be assessed in accordance with § 914(2) above. 

2. A developer who owns condominium units, and who is offering the units for sale, may be excused from payment of assessments against those unsold units for the period of time the developer has guaranteed to all purchasers or other unit owners in the same condominium that assessments will not exceed a stated dollar amount and that the developer will pay any common expenses that exceed the guaranteed amount. Such guarantee may be stated in the purchase contract, declaration, prospectus, or written agreement between the developer and a majority of the unit owners other than the developer and may provide that, after the initial guarantee period, the developer may extend the guarantee for one or more stated periods. If a developer-controlled association has maintained all insurance coverage required by § 909(11)(a) above, common expenses incurred during a guarantee period, as a result of a natural disaster or an act of God occurring during the same guarantee period, which are not covered by the proceeds from such insurance, may be assessed against all unit owners owning units on the date of such natural disaster or act of God, and their successors and assigns, including the developer with respect to units owned by the developer. Any such assessment shall be in accordance with § 914(2) or (4) above, as applicable. 

(b) If the purchase contract, declaration, prospectus, or written agreement between the developer and a majority of unit owners other than the developer provides for the developer to be excused from payment of assessments under paragraph (a), only regular periodic assessments for common expenses as provided for in the declaration and prospectus and disclosed in the estimated operating budget shall be used for payment of common expenses during any period in which the developer is excused. Accordingly, no funds which are receivable from unit purchasers or unit owners and payable to the association, including capital contributions or startup funds collected from unit purchasers at closing, may be used for payment of such common expenses. 

(c) If a developer of a multicondominium is excused from payment of assessments under paragraph (a), the developer's financial obligation to the multicondominium association during any period in which the developer is excused from payment of assessments is as follows: 

1. The developer shall pay the common expenses of a condominium affected by a guarantee, including the funding of reserves as provided in the adopted annual budget of that condominium, which exceed the regular periodic assessments at the guaranteed level against all other unit owners within that condominium. 

2. The developer shall pay the common expenses of a multicondominium association, including the funding of reserves as provided in the adopted annual budget of the association, which are allocated to units within a condominium affected by a guarantee and which exceed the regular periodic assessments against all other unit owners within that condominium. 

(10) The specific purpose or purposes of any special assessment approved in accordance with the condominium documents shall be set forth in a written notice of such assessment sent or delivered to each unit owner. The funds collected pursuant to a special assessment shall be used only for the specific purpose or purposes set forth in such notice. However, upon completion of such specific purpose or purposes, any excess funds will be considered common surplus, and may, at the discretion of the board, either be returned to the unit owners or applied as a credit toward future assessments. 

§ 916. Termination. 
(1) Unless otherwise provided in the declaration, the condominium property may be removed from the provisions of this chapter only by consent of all of the unit owners, evidenced by a recorded instrument to that effect, and upon the written consent by all of the holders of recorded liens affecting any of the condominium parcels. When the board of directors intends to terminate or merge the condominium, or dissolve or merge the association, the board shall so notify the Bureau before taking any action to terminate or merge the condominium or the association. Upon recordation of the instrument evidencing consent of all of the unit owners to terminate the condominium, the association within 30 business days shall notify the Bureau of the termination and the date the document was recorded, and the book and page number of the public records where the document was recorded, and shall provide the Bureau a copy of the recorded termination notice certified by the Clerk of Court. 

(2) Notwithstanding any contrary provision in the declaration or the bylaws, the powers and duties of the directors, or other person or persons appointed by the court pursuant to subsection (4), after the commencement of a termination proceeding include, but are not limited to, the following acts in the name and on behalf of the association: 

(a) To employ directors, agents, and attorneys to liquidate or wind up its affairs. 

(b) To continue the conduct of the affairs of the association insofar as necessary for the disposal or winding up thereof. 

(c) To carry out contracts and collect, pay, compromise, and settle debts and claims for and against the association. 

(d) To defend suits brought against the association. 

(e) To sue in the name of the association, for all sums due or owing to the association or to recover any of its property.

(f) To perform any act necessary to maintain, repair, or demolish unsafe and uninhabitable structures, or other condominium property in compliance with applicable codes. 

(g) To sell at public or private sale, exchange, convey, or otherwise dispose of all or any part of the assets of the association for an amount deemed in the best interest of the association, and to execute bills of sale and deeds of conveyance in the name of the association. 

(h) To collect and receive any and all rents, profits, accounts receivable, income, maintenance fees, special assessments, and insurance proceeds for the association. 

(I) In general, to make contracts and to do any and all things in the name of the association which may be proper or convenient for the purposes of winding up, selling, and liquidating the affairs of the association. 

(3) Unless the declaration or the bylaws provide otherwise, a vacancy in the board during a winding up proceeding, resulting from the resignation or expiration of term of any director, may be filled by a majority vote of the unit owners. 

(4) If, after a natural disaster, the identity of the directors or their right to hold office is in doubt, or if they are dead or unable to act, or if they fail or refuse to act, or their whereabouts cannot be ascertained, any interested person may petition the Supreme Court to determine the identity of the directors, or, if determined to be in the best interest of the unit owners, to appoint a receiver to wind up the affairs of the association after hearing upon such notice to such persons as the court may direct. The receiver shall be vested with those powers as are given to the board of directors pursuant to the declaration and bylaws and subsection (2) and such others which may be necessary to wind up the affairs of the association and set forth in the order of appointment. The appointment of the receiver shall be subject to such bonding requirements as the court may direct in the order of appointment. The order shall also provide for the payment of a reasonable fee for the services of the receiver from the sources identified in the order, which may include rents, profits, incomes, maintenance fees, or special assessments collected from the condominium property. 

(5) After determining that all known debts and liabilities of an association in the process of winding up have been paid or adequately provided for, the board, or other person or persons appointed by the court, pursuant to subsection (4), shall distribute all the remaining assets in the manner set forth in subsection (6). If the winding up is by court proceeding or subject to court supervision, the distribution shall not be made until after the expiration of any period for the presentation of claims that has been prescribed by order of the court. 

(6) Assets held by an association upon a valid condition requiring return, transfer, or conveyance, which condition has occurred or will occur, shall be returned, transferred, or conveyed in accordance with the condition. The remaining assets of an association shall be distributed as follows: 

(a) If the declaration or bylaws provides the manner of disposition the assets shall be disposed in that manner. 

(b) If the declaration or bylaws do not provide the manner of disposition, the assets shall be distributed among the unit owners in accordance with their respective rights therein, as set forth in subsection (7). 

(7) Unless otherwise provided in the declaration as originally recorded, upon removal of the condominium property from the provisions of this chapter, the condominium property is owned by the unit owners in the same shares as each owner previously owned in the common elements. All liens shall be transferred to the share in the condominium property attributable to the unit originally encumbered by the lien in its same priority. 

(8) Distribution may be made either in money or in property or securities and either in installments from time to time or as a whole, if this can be done fairly and ratably and in conformity with the declaration and shall be made as soon as reasonably consistent with the beneficial liquidation of the assets. 

(9) An association that has been terminated nevertheless continues to exist for the purpose of winding up its affairs, prosecuting and defending actions by or against it, and enabling it to collect and discharge obligations, dispose of and convey its property, and collect and divide its assets, but not for the purpose of conducting its activities except so far as necessary for the winding up thereof. 

(10) The termination of a condominium does not bar the creation of another condominium affecting all or any portion of the same property. 

§§ 917-919. [Reserved.] 
PART II 
RIGHTS AND REMEDIES OF OWNERS AND LESSEES 

§ 920. Equitable relief. In the event of substantial damage to or destruction of all or a substantial part of the condominium property, and if the property is not repaired, reconstructed, or rebuilt within a reasonable period of time, any unit owner may petition a court for equitable relief, which may include a termination of the condominium and a partition. 

§ 921. Limitation of liability. 
(1) The liability of the owner of a unit for common expenses is limited to the amounts for which he or she is assessed for common expenses from time to time in accordance with this chapter, the declaration, and bylaws. 

(2) The owner of a unit may be personally liable for the acts or omissions of the association in relation to the use of the common elements, but only to the extent of his or her pro rata share of that liability in the same percentage as his or her interest in the common elements, and then in no case shall that liability exceed the value of his or her unit. 

(3) In any legal action in which the association may be exposed to liability in excess of insurance coverage protecting it and the unit owners, the association shall give notice of the exposure within a reasonable time to all unit owners, and they shall have the right to intervene and defend. 

§ 922. Liens. 
(1) Subsequent to recording the declaration and while the property remains subject to the declaration, no liens of any nature are valid against the condominium property as a whole except with the unanimous consent of the unit owners. During this period, liens may arise or be created only against individual condominium parcels. 

(2) Labor performed on or materials furnished to a unit shall not be the basis for the filing of a lien against the unit or condominium parcel of any unit owner not expressly consenting to or requesting the labor or materials. Labor performed on or materials furnished to the common elements are not the basis for a lien on the common elements, but if authorized by the association, the labor or materials are deemed to be performed or famished with the express consent of each unit owner and may be the basis for the filing of a lien against all condominium parcels in the proportions for which the owners are liable for common expenses. 

(3) If a lien against two or more condominium parcels becomes effective, each owner may relieve his or her condominium parcel of the lien by payment of the proportionate amount attributable to his or her condominium parcel. Upon the payment, the lienor shall release the lien of record for that condominium parcel. 

§923. Right to rescind unconscionable lease; unconscionability of certain leases; rebuttable presumption. 
(1) A lease pertaining to use by condominium unit owners of recreational or other common facilities, irrespective of the date on which such lease was entered into, is presumptively unconscionable and an action may be brought to rescind the lease if all of the following elements exist: 

(a) The lease was executed by persons none of whom at the time of the execution of the lease were elected by condominium unit owners, other than the developer, to represent their interests; 

(b) The lease requires either the condominium association or the condominium unit owners to insure buildings or other facilities on the subject real property against fire or any other hazard; 

(c) The lease requires either the condominium association or the condominium unit owners to perform some or all maintenance obligations pertaining to the subject real property or facilities located upon the subject real property; 

(d) The lease requires either the condominium association or the condominium unit owners to pay rents to the lessor for a period of 21 years or more; 

(e) The lease provides that failure of the lessee to make payments of rents due under the lease either creates, establishes, or permits establishment of a lien upon individual condominium units of the condominium to secure claims for rent;

(f) The lease requires an annual rental which exceeds 25 percent of the appraised value of the leased property as improved, provided that, for purposes of this paragraph, "annual rental" means the amount due during the first twelve months of the lease for all units, regardless of whether such units were in fact occupied or sold during that period, and "appraised value" means the appraised value placed upon the leased property the first tax year after the sale of a unit in the condominium; 

(g) The lease provides for a periodic rental increase; and 

(h) The lease or other condominium documents require that every transferee of a condominium unit must assume obligations under the lease. 

(2) The presumption may be rebutted by a lessor upon the showing of additional facts and circumstances to justify and validate what otherwise appears to be an unconscionable lease under this section. Failure of a lease to contain all the enumerated elements shall neither preclude a determination of unconscionability of the lease nor raise a presumption as to its conscionability. This section does not create any new cause of action to invalidate any condominium lease, but shall operate as a statutory prescription on procedural matters in actions brought on one or more causes of action existing at the time of the execution of such lease. 

(3) Any provision of the Palau National Code to the contrary notwithstanding, neither the statute of limitations nor laches shall prohibit unit owners from maintaining a cause of action under the provisions of this section. 

§ 924. Right of owners to peaceably assemble. 
(1) All common elements, common areas, and recreational facilities serving any condominium shall be available to unit owners in the condominium or condominiums served thereby and their invited guests for the use intended for such common elements, common areas, and recreational facilities, subject to the provisions of § 905(4) above. The entity or entities responsible for the operation of the common elements, common areas, and recreational facilities may adopt reasonable rules and regulations pertaining to the use of such common elements, common areas, and recreational facilities. No entity or entities shall unreasonably restrict any unit owner's right to peaceably assemble or right to invite public officers or candidates for public office to appear and speak in common elements, common areas, and recreational facilities. 

(2) Any owner prevented from exercising rights guaranteed by subsection (1) may bring a court action, and, upon favorable adjudication, the court shall enjoin the enforcement of any provision contained in any condominium document or rule which operates to deprive the owner of such rights. 

§ 925. Cable television service; resident's right to access without extra charge. No resident of any condominium dwelling unit, whether tenant or owner, shall be denied access to any available franchised or licensed cable television service, nor shall such resident or cable television service be required to pay anything of value in order to obtain or provide such service except those charges normally paid for like services by residents of, or providers of such services to, single-family homes within the same franchised or licensed area and except for installation charges as such charges may be agreed to between such resident and the provider of such services. 

§ 926. Limitation on actions by association. The statute of limitations for any actions in law or equity which a condominium association or a cooperative association may have shall not begin to run until the unit owners have elected a majority of the members of the board of administration. 

§ 927. Attorney's fees. If a contract or lease between a condominium unit owner or association and a developer contains a provision allowing attorney's fees to the developer, should any litigation arise under the provisions of the contract or lease, the court shall also allow reasonable attorney's fees to the unit owner or association when the unit owner or association prevails in any action by or against the unit owner or association with respect to the contract or lease. 

§ 928. Condominiums as residential property. For the purpose of property and casualty insurance risk classification, condominiums shall be classed as residential property. 

§ 929. [Reserved] 
PART III 
RIGHTS AND OBLIGATIONS OF DEVELOPERS 

§ 930. Sales or reservation deposits prior to closing. 
(1) If a developer contracts to sell a condominium parcel and the construction, furnishing, and landscaping of the property submitted or proposed to be submitted to condominium ownership has not been substantially completed in accordance with the plans and specifications and representations made by the developer in the disclosures required by this chapter, the developer shall pay into an escrow account all payments up to 10 percent of the sale price received by the developer from the buyer towards the sale price. The escrow agent shall give to the purchaser a receipt for the deposit, upon request. In lieu of the foregoing, the Bureau director has the discretion to accept other assurances, including, but not limited to, a surety bond or an irrevocable letter of credit in an amount equal to the escrow requirements of this section. Default determinations and refund of deposits shall be governed by the escrow release provision of this subsection. Funds shall be released from escrow as follows: 

(a) If a buyer properly terminates the contract pursuant to its terms or pursuant to this chapter, the funds shall be paid to the buyer together with any interest earned. 

(b) If the buyer defaults in the performance of his or her obligations under the contract of purchase and sale, the funds shall be paid to the developer together with any interest eared. 

(c) If the contract does not provide for the payment of any interest earned on the escrowed funds, interest shall be paid to the developer at the closing of the transaction. 

(d) If the funds of a buyer have not been previously disbursed in accordance with the provisions of this subsection, they may be disbursed to the developer by the escrow agent at the closing of the transaction, unless prior to the disbursement and the conveyance of the property to the buyer the escrow agent receives from the buyer written notice of a dispute between the buyer and developer. 

(2) All payments which are in excess of the ten percent of the sale price described in subsection (1) and which have been received prior to completion of construction by the developer from the buyer on a contract for purchase of a condominium parcel shall be held in a special escrow account established as provided in subsection (1) and controlled by an attorney who is licensed to practice in the Republic and may not be used by the developer prior to closing the transaction, except as provided in subsection (3) or except for refund to the buyer. If the money remains in this special account for more than three months and earns interest, the interest shall be paid as provided in subsection (1). 

(3) If the contract for sale of the condominium unit so provides, the developer may withdraw escrow funds in excess of ten percent of the purchase price from the special account required by subsection (2) when the construction of improvements has begun. He or she may use the funds in the actual construction and development of the condominium property in which the unit to be sold is located, including payment for improvements, appliances, furniture, furnishings, equipment, other personal property for the condominium, surveyors, architects, landscape architects, engineers, and other design professionals, and interest and finance charges under any construction loan. However, no part of these funds may be used for salaries, commissions, or expenses of salespersons or for advertising purposes. Additionally, prior to the developer utilizing escrow funds for construction, the developer shall obtain a separate construction contract and a budget for the construction project. A contract which permits use of the advance payments for these purposes shall include the following legend conspicuously printed or stamped in boldfaced type on the first page of the contract and immediately above the place for the signature of the buyer: ANY PAYMENT IN EXCESS OF TEN PERCENT OF THE PURCHASE PRICE MADE TO DEVELOPER PRIOR TO CLOSING PURSUANT TO THIS CONTRACT MAY BE USED FOR CONSTRUCTION PURPOSES BY THE DEVELOPER. 

(4) The term "completion of construction" means issuance of a certificate of occupancy for the entire building or improvement, or the equivalent authorization issued by the governmental body having jurisdiction, and, in a jurisdiction where no certificate of occupancy or equivalent authorization is issued, it means substantial completion of construction, finishing, and equipping of the building or improvements according to the plans and specifications. 

(5) The failure to comply with the provisions of this section renders the contract voidable by the buyer, and, if voided, all sums deposited or advanced under the contract shall be refunded with interest at the highest rate then being paid on savings accounts, excluding certificates of deposit, by savings and loan associations in the area in which the condominium property is located. 

(6) If a developer enters into a reservation agreement, the developer shall pay into an escrow account all reservation deposit payments. Reservation deposits shall be payable to the escrow agent, who shall give to the prospective purchaser a receipt for the deposit, acknowledging that the deposit is being held pursuant to the requirements of this subsection. The funds may be placed in either interest-bearing or non-interest-bearing accounts, provided that the funds shall at all reasonable times be available for withdrawal in full by the escrow agent. The developer shall maintain separate records for each condominium or proposed condominium for which deposits are being accepted. Upon written request to the escrow agent by the prospective purchaser or developer, the funds shall be immediately and without qualification refunded in full to the prospective purchaser. Upon such refund, any interest shall be paid to the prospective purchaser, unless otherwise provided in the reservation agreement. A reservation deposit shall not be released directly to the developer. In cases where the reservation deposit is to be used as a down payment on the purchase price simultaneously with or subsequent to the execution of a contract, the deposit shall be transferred directly to the escrow account for the purchase contract. Upon the execution of a purchase agreement for a unit, any funds paid by the purchaser as a deposit to reserve the unit pursuant to a reservation agreement, and any interest thereon, shall cease to be subject to the provisions of this subsection and shall instead be subject to the provisions of subsections (1)-(5). 

(7) Any developer who willfully fails to comply with the provisions of this section concerning establishment of an escrow account, deposits of funds into escrow, and withdrawal of funds from escrow is guilty of a felony. The failure to establish an escrow account or to place funds in an escrow account is prima facie evidence of an intentional and purposeful violation of this section. 

(8) Every escrow account required by this section shall be established with a financial institution having a net worth in excess of $5 million or insured by the United States Federal Deposit Insurance Corporation. The escrow agent shall not be located outside the Republic of Palau unless, pursuant to the escrow agreement, the escrow agent submits to the jurisdiction of the Bureau and the courts of the Republic of Palau for any cause of action arising from the escrow. Every escrow agent shall be independent of the developer, and no developer or any officer, director, affiliate, subsidiary, or employee of a developer may serve as escrow agent. Escrow funds may be invested only in institutions the deposits of which are insured by the Federal Deposit Insurance Corporation.

(9) Nothing in this section shall be construed to require any filing with the Bureau in the case of condominiums other than residential condominiums. 

§ 931. Warranties. 
(1) The developer shall be deemed to have granted to the purchaser of each unit an implied warranty of fitness and merchantability for the purposes or uses intended as follows: 

(a) As to each unit, a warranty for three years commencing with the initial occupancy of the unit. 

(b) As to the personal property that is transferred with, or appurtenant to, each unit, a warranty which is for the same period as that provided by the manufacturer of the personal property, commencing with the date of closing of the purchase or the date of possession of the unit, whichever is earlier. 

(c) As to all other improvements for the use of unit owners, a three-year warranty commencing with the date of completion of the improvements. 

(d) As to all other personal property for the use of unit owners, a warranty which shall be the same as that provided by the manufacturer of the personal property. 

(e) As to the roof and structural components of a building or other improvements and as to mechanical, electrical, and plumbing elements serving improvements or a building, except mechanical elements serving only one unit, a warranty for a period beginning with the completion of construction of each building or improvement and continuing for three years thereafter or one year after owners other than the developer obtain control of the association, whichever occurs last, but in no event more than 5 years. 

(f) As to all other property which is conveyed with a unit, a warranty to the initial purchaser of each unit for a period of one year from the date of closing of the purchase or the date of possession, whichever occurs first. 

(2) The contractor, and all subcontractors and suppliers, grant to the developer and to the purchaser of each unit implied warranties of fitness as to the work performed or materials supplied by them as follows: 

(a) For a period of three years from the date of completion of construction of a building or improvement, a warranty as to the roof and structural components of the building or improvement and mechanical and plumbing elements serving a building or an improvement, except mechanical elements serving only one unit. 

(b) For a period of one year after completion of all construction, a warranty as to all other improvements and materials. 

(3) "Completion of a building or improvement" means substantial completion of construction, finishing, and equipping of the building or improvement according to the plans and specifications. 

(4) These warranties are conditioned upon routine maintenance being performed, unless the maintenance is an obligation of the developer or a developer-controlled association. 

(5) The warranties provided by this section shall inure to the benefit of each owner and his or her successor owners and to the benefit of the developer. 

(6) Residential condominiums maybe covered by an insured warranty program underwritten by a licensed insurance company, provided that such warranty program meets the minimum requirements of this chapter; to the degree that such warranty program does not meet the minimum requirements of this chapter, such requirements shall apply. 
 
§§ 932-939. [Reserved] 
 PART IV 
RIGHTS AND OBLIGATIONS OF ASSOCIATION 
§ 940. Transfer of association control. 
(1) When unit owners other than the developer own 15 percent or more of the units in a condominium that will be operated ultimately by an association, the unit owners other than the developer shall be entitled to elect no less than one-third of the members of the board of administration of the association. Unit owners other than the developer are entitled to elect not less than a majority of the members of the board of administration of an association: 

(a) Three years after 50 percent of the units that will be operated ultimately by the association have been conveyed to purchasers; 

(b) Three months after 90 percent of the units that will be operated ultimately by the association have been conveyed to purchasers; 

(c) When all the units that will be operated ultimately by the association have been completed, some of them have been conveyed to purchasers, and none of the others are being offered for sale by the developer in the ordinary course of business; 

(d) When some of the units have been conveyed to purchasers and none of the others are being constructed or offered for sale by the developer in the ordinary course of business; or 

(e) Seven years after recordation of the declaration of condominium; or, in the case of an association which may ultimately operate more than one condominium, seven years after recordation of the declaration for the first condominium it operates; or, in the case of an association operating a phase condominium created pursuant to § 953 below, seven years after recordation of the declaration creating the initial phase, whichever occurs first. The developer is entitled to elect at least one member of the board of administration of an association as long as the developer holds for sale in the ordinary course of business at least five percent, in condominiums with fewer than 200 units, and two percent, in condominiums with more than 200 units, of the units in a condominium operated by the association. Following the time the developer relinquishes control of the association, the developer may exercise the right to vote any developer-owned units in the same manner as any other unit owner except for purposes of reacquiring control of the association or selecting the majority members of the board of administration. 

(2) Within 75 days after the unit owners other than the developer are entitled to elect a member or members of the board of administration of an association, or in the event the developer gives written notice to the association that the developer elects to terminate the developer control period, within 75 days after the receipt of the notice, the association shall call, and give not less than 60 days' notice of an election for the members of the board of administration. The election shall proceed as provided in § 910(2)(d) above. The notice may be given by any unit owner if the association fails to do so. Upon election of the first unit owner other than the developer to the board of administration, the developer shall forward to the Bureau the name and mailing address of the unit owner board member. 

(3) If a developer holds units for sale in the ordinary course of business, none of the following actions may be taken without approval in writing by the developer: 

(a) Assessment of the developer as a unit owner for capital improvements. 

(b) Any action by the association that would be detrimental to the sales of units by the developer. However, an increase in assessments for common expenses without discrimination against the developer shall not be deemed to be detrimental to the sales of units. 

(4) At the time that unit owners other than the developer elect a majority of the members of the board of administration of an association, the developer shall relinquish control of the association, the unit owners shall accept control, and the developer control period shall end. Simultaneously, or for the purposes of paragraph (c) not more than 90 days thereafter, the developer shall deliver to the association, at the developer's expense, all property of the unit owners and of the association which is held or controlled by the developer, including, but not limited to, the following items, if applicable, as to each condominium operated by the association: 

(a) 	1. The original or a photocopy of the recorded declaration of condominium and all amendments thereto. If a photocopy is provided, it shall be certified by affidavit of the developer or an officer or agent of the developer as being a complete copy of the actual recorded declaration. 

2. A certified copy of the articles of incorporation of the association or, if the association was created prior to the effective date of this act and it is not incorporated, copies of the documents creating the association. 

3. A certified copy of the bylaws. 

4. The minute books, including all minutes, and other books and records of the association, if any. 

5. Any house rules and regulations which have been promulgated. 

(b) Resignations of officers and members of the board of administration who are required to resign because the developer is required to relinquish control of the association. 

(c) The financial records, including financial statements of the association, and source documents from the incorporation of the association through the date of turnover. The records shall be audited for the period from the incorporation of the association or from the period covered by the last audit, if an audit has been performed for each fiscal year since incorporation, by an independent certified public accountant. All financial statements shall be prepared in accordance with generally accepted accounting principles and shall be audited in accordance with generally accepted auditing standards. The accountant performing the audit shall examine to the extent necessary supporting documents and records, including the cash disbursements and related paid invoices to determine if expenditures were for association purposes and the billings, cash receipts, and related records to determine that the developer was charged and paid the proper amounts of assessments. 

(d) Association funds or control thereof. 

(e) All tangible personal property that is property of the association, which is represented by the developer to be part of the common elements or which is ostensibly part of the common elements, and an inventory of that property. 

(f) A copy of the plans and specifications utilized in the construction or remodeling of improvements and the supplying of equipment to the condominium and in the construction and installation of all mechanical components serving the improvements and the site with a certificate in affidavit form of the developer or the developer's agent or an architect or engineer authorized to practice in the Republic of Palau that such plans and specifications represent, to the best of his or her knowledge and belief, the actual plans and specifications utilized in the construction and improvement of the condominium property and for the construction and installation of the mechanical components serving the improvements. If the condominium property has been declared a condominium more than three years after the completion of construction or remodeling of the improvements, the requirements of this paragraph do not apply. 

(g) A list of the names and addresses, of which the developer had knowledge at any time in the development of the condominium, of all contractors, subcontractors, and suppliers utilized in the construction or remodeling of the improvements and in the landscaping of the condominium or association property. 

(h) Insurance policies. 

(I) Copies of any certificates of occupancy which may have been issued for the condominium property. 

(j) Any other permits applicable to the condominium property which have been issued by governmental bodies and are in force or were issued within one year prior to the date the unit owners other than the developer take control of the association. 

(k) All written warranties of the contractor, subcontractors, suppliers, and manufacturers, if any, that are still effective. 

(l) A roster of unit owners and their addresses and telephone numbers, if known, as shown on the developer's records. 

(m) Leases of the common elements and other leases to which the association is a party. 

(n) Employment contracts or service contracts in which the association is one of the contracting parties or service contracts in which the association or the unit owners have an obligation or responsibility, directly or indirectly, to pay some or all of the fee or charge of the person or persons performing the service. 

(o) All other contracts to which the association is a party. 

(5) If, during the period prior to the time that the developer relinquishes control of the association pursuant to subsection (4), any provision of the this Act or any rate promulgated hereunder is violated by the association, the developer is responsible for such violation and is subject to the administrative action provided in this chapter for such violation or violations and is liable for such violation or violations to third parties. 

(6) The Bureau shall adopt rules pursuant to the Administrative Procedure Act to ensure the efficient and effective transition from developer control of a condominium to the establishment of a unit-owner controlled association.

§ 941. Agreements entered into by the association. 
(1) Any grant or reservation made by a declaration, lease, or other document, and any contract made by an association prior to assumption of control of the association by unit owners other than the developer, that provides for operation, maintenance, or management of a condominium association or property serving the unit owners of a condominium shall be fair and reasonable, and such grant, reservation, or contract may be canceled by unit owners other than the developer: 

(a) If the association operates only one condominium and the unit owners other than the developer have assumed control of the association, or if unit owners other than the developer own not less than 75 percent of the voting interests in the condominium, the cancellation shall be by concurrence of the owners of not less than 75 percent of the voting interests other than the voting interests owned by the developer. If a grant, reservation, or contract is so canceled and the unit owners other than the developer have not assumed control of the association, the association shall make a new contract or otherwise provide for maintenance, management, or operation in lieu of the canceled obligation, at the direction of the owners of not less than a majority of the voting interests in the condominium other than the voting interests owned by the developer. 

(b) If the association operates more than one condominium and the unit owners other than the developer have not assumed control of the association, and if unit owners other than the developer own at least 75 percent of the voting interests in a condominium operated by the association, any grant, reservation, or contract for maintenance, management, or operation of buildings containing the units in that condominium or of improvements used only by unit owners of that condominium may be canceled by concurrence of the owners of at least 75 percent of the voting interests in the condominium other than the voting interests owned by the developer. No grant, reservation, or contract for maintenance, management, or operation of recreational areas or any other property serving more than one condominium, and operated by more than one association, may be canceled except pursuant to paragraph (d). 

(c) If the association operates more than one condominium and the unit owners other than the developer have assumed control of the association, the cancellation shall be by concurrence of the owners of not less than 75 percent of the total number of voting interests in all condominiums operated by the association other than the voting interests owned by the developer. 

(d) If the owners of units in a condominium have the right to use property in common with owners of units in other condominiums and those condominiums are operated by more than one association, no grant, reservation, or contract for maintenance, management, or operation of the property serving more than one condominium may be canceled until unit owners other than the developer have assumed control of all of the associations operating the condominiums that are to be served by the recreational area or other property, after which cancellation may be effected by concurrence of the owners of not less than 75 percent of the total number of voting interests in those condominiums other than voting interests owned by the developer. 

(2) Any grant or reservation made by a declaration, lease, or other document, or any contract made by the developer or association prior to the time when unit owners other than the developer elect a majority of the board of administration, which grant, reservation, or contract requires the association to purchase condominium property or to lease condominium property to another party, shall be deemed ratified unless rejected by a majority of the voting interests of unit owners other than the developer within 18 months after unit owners other than the developer elect a majority of the board of administration. This subsection does not apply to any grant or reservation made by a declaration whereby persons other than the developer or the developer's heirs, assigns, affiliates, directors, officers, or employees are granted the right to use the condominium property, so long as such persons are obligated to pay, at a minimum, a proportionate share of the cost associated with such property. 

(3) Any grant or reservation made by a declaration, lease, or other document, and any contract made by an association, whether before or after assumption of control of the association by unit owners other than the developer, that provides for operation, maintenance, or management of a condominium association or property serving the unit owners of a condominium shall not be in conflict with the powers and duties of the association or the rights of the unit owners as provided in this chapter. 

(4) Any grant or reservation made by a declaration, lease, or other document, and any contract made by an association prior to assumption of control of the association by unit owners other than the developer, shall be fair and reasonable. 

(5) It is declared that the public policy of the Republic of Palau prohibits the inclusion or enforcement of escalation clauses in management contracts for condominiums, and such clauses are hereby declared void for public policy. For the purposes of this section, an escalation clause is any clause in a condominium management contract which provides that the fee under the contract shall increase at the same percentage rate as any recognized and conveniently available commodity or consumer price index. 

(6) Any action to compel compliance with the provisions of this section or of § 940 above maybe brought pursuant to court action. In any such action brought to compel compliance with the provisions of § 940, the prevailing party is entitled to recover reasonable attorney's fees. 

§ 942. Agreements for operation, maintenance, or management of condominiums; specific requirements. 
(1) No written contract between a party contracting to provide maintenance or management services and an association which contract provides for operation, maintenance, or management of a condominium association or property serving the unit owners of a condominium shall be valid or enforceable unless the contract: 

(a) Specifies the services, obligations, and responsibilities of the party contracting to provide maintenance or management services to the unit owners. 

(b) Specifies those costs incurred in the performance of those services, obligations, or responsibilities which are to be reimbursed by the association to the party contracting to provide maintenance or management services. 

(c) Provides an indication of how often each service, obligation, or responsibility is to be performed, whether stated for each service, obligation, or responsibility or in categories thereof. 

(d) Specifies a minimum number of personnel to be employed by the party contracting to provide maintenance or management services for the purpose of providing service to the association. 

(e) Discloses any financial or ownership interest which the developer, if the developer is in control of the association, holds with regard to the party contracting to provide maintenance or management services. 

(2) In any case in which the party contracting to provide maintenance or management services fails to provide such services in accordance with the contract, the association is authorized to procure such services from some other party and shall be entitled to collect any fees or charges paid for service performed by another party from the party contracting to provide maintenance or management services. 

(3) Any services or obligations not stated on the face of the contract shall be unenforceable. 

(4) Notwithstanding the fact that certain vendors contract with associations to maintain equipment or property which is made available to serve unit owners, it is the intent of the Olbiil Era Kelulau that this section applies to contracts for maintenance or management services for which the association pays compensation. This section does not apply to contracts for services or property made available for the convenience of unit owners by lessees or licensees of the association, such as coin-operated laundry, food, soft drink, or telephone vendors; cable television operators; retail store operators; businesses; restaurants; or similar vendors. 

§ 943. Contracts for products and services; in writing; bids; exceptions. Associations with less than 50 units may opt out of the provisions of this section if two-thirds of the unit owners vote to do so, which opt-out may be accomplished by a proxy specifically setting forth the exception from this section. 

(1) All contracts as further described herein or any contract that is not to be fully performed within one year after the making thereof, for the purchase, lease, or renting of materials or equipment to be used by the association in accomplishing its purposes under this chapter, and all contracts for the provision of services, shall be in writing. If a contract for the purchase, lease, or renting of materials or equipment, or for the provision of services, requires payment by the association on behalf of any condominium operated by the association in the aggregate that exceeds five percent of the total annual budget of the association, including reserves, the association shall obtain competitive bids for the materials, equipment, or services. Nothing contained herein shall be construed to require the association to accept the lowest bid. 

(2) (a)	1. Notwithstanding the foregoing, contracts with employees of the association, and contracts for attorney, accountant, architect, community association manager, engineering, and landscape architect services are not subject to the provisions of this section. 

2. If a contract was awarded under the competitive bid procedures of this section, any renewal of that contract is not subject to such competitive bid requirements if the contract contains a provision that allows the board to cancel the contract on 30 days' notice. A contract with a manager, if made by a competitive bid, may be made for up to three years. A condominium whose declaration or bylaws provides for competitive bidding for services may operate under the provisions of that declaration or bylaws in lieu of this section if those provisions are not less stringent than the requirements of this section. 

(b) Nothing contained herein is intended to limit the ability of an association to obtain needed products and services in an emergency. 

(c) This section shall not apply if the business entity with which the association desires to enter into a contract is the only source of supply within the Republic. 

(d) Nothing contained herein shall excuse a party contracting to provide maintenance or management services from compliance with § 942 above. 

§ 944. Obligations of owners; waiver; levy of fine against unit by association. 
(1) Each unit owner, each tenant and other invitee, and each association shall be governed by, and shall comply with the provisions of, this chapter, the declaration, the documents creating the association, and the association bylaws and the provisions thereof shall be deemed expressly incorporated into any lease of a unit. Actions for damages or for injunctive relief, or both, for failure to comply with these provisions may be brought by the association or by a unit owner against: 

(a) The association. 

(b) A unit owner. 

(c) Directors designated by the developer, for actions taken by them prior to the time control of the association is assumed by unit owners other than the developer. 

(d) Any director who willfully and knowingly fails to comply with these provisions. 

(e) Any tenant leasing a unit, and any other invitee occupying a unit. 

The prevailing party in any such action or in any action in which the purchaser claims a right of voidability based upon contractual provisions as required in § 962(1)(a) below is entitled to recover reasonable attorney's fees. A unit owner prevailing in an action between the association and the unit owner under this section, in addition to recovering his or her reasonable attorney's fees, may recover additional amounts as determined by the court to be necessary to reimburse the unit owner for his or her share of assessments levied by the association to fund its expenses of the litigation. This relief does not exclude other remedies provided by law. 

(2) A provision of this chapter may not be waived if the waiver would adversely affect the rights of a unit owner or the purpose of the provision, except that unit owners or members of a board of administration may waive notice of specific meetings in writing if provided by the bylaws. Any instruction given in writing by a unit owner or purchaser to an escrow agent may be relied upon by an escrow agent, whether or not such instruction and the payment of funds thereunder might constitute a waiver of any provision of this chapter. 

(3) If the declaration or bylaws so provide, the association may levy reasonable fines against a unit for the failure of the owner of the unit, or its occupant, licensee, or invitee, to comply with any provision of the declaration, the association bylaws, or reasonable rules of the association. No fine will become a lien against a unit. No fine may exceed $100 per violation. However, a fine may be levied on the basis of each day of a continuing violation, with a single notice and opportunity for hearing, provided that no such fine shall in the aggregate exceed $1,000. No fine may be levied except after giving reasonable notice and opportunity for a hearing to the unit owner and, if applicable, its licensee or invitee. The hearing must beheld before a committee of other unit owners. If the committee does not agree with the fine, the fine may not be levied. The provisions of this subsection do not apply to unoccupied units.

§§ 945-949. [Reserved] 
 PART V 
SPECIAL TYPES OF CONDOMINIUMS 

§ 950. Leaseholds. 
(1) A condominium may be created on lands held under lease or may include recreational facilities or other common elements or commonly used facilities on a leasehold if, on the date the first unit is conveyed by the developer to a bona fide purchaser, the lease has an unexpired term of at least 50 years. However, if the condominium constitutes a nonresidential condominium or commercial condominium, the lease shall have an unexpired term of at least 30 years. If rent under the lease is payable by the association or by the unit owners, the lease shall include the following requirements: 

(a) The leased land must be identified by a description that is sufficient to pass title, and the leased personal property must be identified by a general description of the items of personal property and the approximate number of each item of personal property that the developer is committing to furnish for each room or other facility. In the alternative, the personal property may be identified by a representation as to the minimum amount of expenditure that will be made to purchase the personal property for the facility. Unless the lease is of a unit, the identification of the land shall be supplemented by a survey showing the relation of the leased land to the land included in the common elements. This provision shall not prohibit adding additional land or personal property in accordance with the terms of the lease, provided there is no increase in rent or material increase in maintenance costs to the individual unit owner. 

(b) The lease shall not contain a reservation of the right of possession or control of the leased property by the lessor or any person other than unit owners or the association and shall not create rights to possession or use of the leased property in any parties other than the association or unit owners of the condominium to be served by the leased property, unless the reservations and rights created are conspicuously disclosed. Any provision for use of the leased property by anyone other than unit owners of the condominium to be served by the leased property shall require the other users to pay a fair and reasonable share of the maintenance and repair obligations and other exactions due from users of the leased property. 

(c) The lease shall state the minimum number of unit owners that will be required, directly or indirectly, to pay the rent under the lease and the maximum number of units that will be served by the leased property. The limitation of the number of units to be served shall not preclude enlargement of the facilities leased and an increase in their capacity, if approved by the association operating the leased property after unit owners other than the developer have assumed control of the association. The provisions of this paragraph do not apply if the lessor is the Government of the Republic of Palau or any political subdivision thereof or any agency of any political subdivision thereof. 

(d) 1. In any action by the lessor to enforce a lien for rent payable or in any action by the association or a unit owner with respect to the obligations of the lessee or the lessor under the lease, the unit owner or the association may raise any issue or interpose any defense, legal or equitable, that he or she or it may have with respect to the lessor's obligations under the lease. If the unit owner or the association initiates any action or interposes any defense other than payment of rent under the lease, the unit owner or the association shall, upon service of process upon the lessor, pay into the registry of the court any allegedly accrued rent and the rent which accrues during the pendency of the proceeding, when due. If the unit owner or the association fails to pay the rent into the registry of the court, the failure constitutes an absolute waiver of the unit owner's or association's defenses other than payment, and the lessor is entitled to default. The unit owner or the association shall notify the lessor of any deposits. When the unit owner or the association has deposited the required funds into the registry of the court, the lessor may apply to the court for disbursement of all or part of the funds shown to be necessary for the payment of taxes, mortgage payments, maintenance and operating expenses, and other necessary expenses incident to maintaining and equipping the leased facilities or necessary for the payment of other expenses arising out of personal hardship resulting from the loss of rental income from the leased facilities. The court, after an evidentiary hearing, may award all or part of the funds on deposit to the lessor for such purpose. The court shall require the lessor to post bond or other security, as a condition to the release of funds from the registry, when the value of the leased land and improvements, apart from the lease itself, is inadequate to fully secure the sum of existing encumbrances on the leased property and the amounts released from the court registry. 

2. When the association or unit owners have deposited funds into the registry of the court pursuant to this subsection and the unit owners and association have otherwise complied with their obligations under the lease or agreement, other than paying rent into the registry of the court rather than to the lessor, the lessor cannot hold the association or unit owners in default on their rental payments nor may the lessor file liens or initiate foreclosure proceedings against unit owners. If the lessor, in violation of this subsection, attempts such liens or foreclosures, then the lessor may be liable for damages plus attorney's fees and costs that the association or unit owners incurred in satisfying those liens or foreclosures. 

(e) If the lease is of recreational facilities or other commonly used facilities that are not completed, rent shall not commence until some of the facilities are completed. Until all of the facilities leased are completed, rent shall be prorated and paid only for the completed facilities in the proportion that the value of the completed facilities bears to the estimated value, when completed, of all of the facilities that are leased. The facilities shall be complete when they have been constructed, finished, and equipped and are available for use. 

(f) 	1. A lease of recreational or other commonly used facilities entered into by the association or unit owners prior to the time when the control of the association is turned over to unit owners other than the developer shall grant to the lessee an option to purchase the leased property, payable in cash, on any anniversary date of the beginning of the lease term after the tenth anniversary, at a price then determined by agreement. 

2. If the lessor wishes to sell his or her interest and has received a bona fide offer to purchase it, the lessor shall send the association and each unit owner a copy of the executed offer. For 90 days following receipt of the offer by the association or unit owners, the association or unit owners have the option to purchase the interest on the terms and conditions in the offer. The option shall be exercised, if at all, by notice in writing given to the lessor within the 90-day period. If the association or unit owners do not exercise the option, the lessor shall have the right, for a period of 90 days after the 90-day period has expired, to complete the transaction described in the offer to purchase. If for any reason such transaction is not concluded within the 90 days, the offer shall have been abandoned, and the provisions of this subsection shall be reimposed. 

3. The option shall be exercised upon approval by owners of two-thirds of the units served by the leased property. 

4. The provisions of this paragraph do not apply to a nonresidential condominium and do not apply if the lessor is the Republic of Palau or any political subdivision thereof or, in the case of an underlying land lease, a person or entity which is not the developer or directly or indirectly owned or controlled by the developer and did not obtain, directly or indirectly, ownership of the leased property from the developer. 

(g) The lease or a subordination agreement executed by the lessor must provide either: 

1. That any lien which encumbers a unit for rent or other moneys or exactions payable is subordinate to any mortgage held by an institutional lender, or 

2. That, upon the foreclosure of any mortgage held by an institutional lender or upon delivery of a deed in lieu of foreclosure, the lien for the unit owner's share of the rent or other exactions shall not be extinguished but shall be foreclosed and unenforceable against the mortgagee with respect to that unit's share of the rent and other exactions which mature or become due and payable on or before the date of the final judgment of foreclosure, in the event of foreclosure, or on or before the date of delivery of the deed in lieu of foreclosure. The lien may, however, automatically and by operation of the lease or other instrument, reattach to the unit and secure the payment of the unit's proportionate share of the rent or other exactions coming due subsequent to the date of final decree of foreclosure or the date of delivery of the deed in lieu of foreclosure. 

The provisions of this paragraph do not apply if the lessor is the Government of the Republic of Palau or any political subdivision thereof or any agency of any political subdivision thereof. 

(2) If rent under the lease is a fixed amount for the full duration of the lease, and the rent thereunder is payable by a person or persons other than the association or the unit owners, the Bureau director has the discretion to accept alternative assurances which are sufficient to secure the payment of rent, including, but not limited to, annuities with an insurance company authorized to do business in the Republic of Palau, the beneficiary of which shall be the association, or cash deposits in trust, the beneficiary of which shall be the association, which deposit shall be in an amount sufficient to generate interest sufficient to meet lease payments as they occur. If alternative assurances are accepted by the Bureau director, the following provisions are applicable: 

(a) Disclosures contemplated by paragraph (1)(b), if not contained within the lease, may be made by the developer. 

(b) Disclosures as to the minimum number of unit owners that will be required, directly or indirectly, to pay the rent under the lease and the maximum number of units that will be served by the leased property, if not contained in the lease, may be stated by the developer. 

(c) The provisions of paragraphs (1)(d) and (e) apply but are not required to be stated in the lease. 

(d) The provisions of paragraph (1)(g) do not apply. 

§ 951. Condominium leases; escalation clauses.
(1) It is declared that the public policy of the Republic of Palau prohibits the inclusion or enforcement of escalation clauses in land leases or other leases or agreements for recreational facilities, land, or other commonly used facilities serving residential condominiums, and such clauses are hereby declared void for public policy. For the purposes of this section, an escalation clause is any clause in a condominium lease or agreement which provides that the rental under the lease or agreement shall increase at the same percentage rate as any recognized and conveniently available commodity or consumer price index. 

(2) The provisions of this section do not apply if the lessor is the Government of the Republic of Palau or any political subdivision thereof or any agency of any political subdivision thereof. 

§ 952. Conversion of existing improvements to condominium. 
A developer may create a condominium by converting existing, previously occupied improvements to such ownership by complying with part I of this chapter. 

§ 953. Phase condominiums. 
(1) A developer may develop a condominium in phases, if the original declaration of condominium submitting the initial phase to condominium ownership or an amendment to the declaration which has been approved by all of the unit owners and unit mortgagees provides for and describes in detail all anticipated phases; the impact, if any, which the completion of subsequent phases would have upon the initial phase; and the time period (which may not exceed seven years from the date of recording the declaration of condominium) within which all phases must be added to the condominium and comply with the requirements of this section and at the end of which the right to add additional phases expires. 

(2) The original declaration of condominium, or an amendment to the declaration, which amendment has been approved by all unit owners and unit mortgagees and the developer, shall describe: 

(a) The land which may become part of the condominium and the land on which each phase is to be built. The descriptions shall include metes and bounds or other legal descriptions of the land for each phase, plot plans, and surveys. Plot plans, attached as an exhibit, must show the approximate location of all existing and proposed buildings and improvements that may ultimately be contained within the condominium. The plot plan may be modified by the developer as to unit or building types to the extent that such changes are described in the declaration. If provided in the declaration, the developer may make nonmaterial changes in the legal description of a phase. 

(b) The minimum and maximum numbers and general size of units to be included in each phase. The general size may be expressed in terms of minimum and maximum square feet. In stating the minimum and maximum numbers of units, the difference between the minimum and maximum numbers shall not be greater than 20 percent of the maximum. 

(c) Each unit's percentage of ownership in the common elements as each phase is added. In lieu of describing specific percentages, the declaration or amendment may describe a formula for reallocating each unit's proportion or percentage of ownership in the common elements and manner of sharing common expenses and owning common surplus as additional units are added to the condominium by the addition of any land. The basis for allocating percentage of ownership among units in added phases shall be consistent with the basis for allocation made among the units originally in the condominium. 

(d) The recreational areas and facilities which will be owned as common elements by all unit owners and all personal property to be provided as each phase is added to the condominium and those facilities or areas which may not be built or provided if any phase or phases are not developed and added as a part of the condominium. The developer may reserve the right to add additional common-element recreational facilities if the original declaration contains a description of each type of facility and its proposed location. The declaration shall set forth the circumstances under which such facilities will be added. 

(e) The membership vote and ownership in the association attributable to each unit in each phase and the results if any phase or phases are not developed and added as a part of the condominium. 

(3) The developer shall notify owners of existing units of the decision not to add one or more additional phases. Notice shall be by first-class mail addressed to each owner at the address of his or her unit or at his or her last known address. 

(4) If one or more phases are not built, the units which are built are entitled to 100 percent ownership of all common elements within the phases actually developed and added as a part of the condominium. 

(5) If the declaration requires the developer to convey any additional lands or facilities to the condominium after the completion of the first phase and he or she fails to do so within the time specified, or within a reasonable time if none is specified, then any owner of a unit or the association may enforce such obligations against the developer or bring an action against the developer for damages caused by the developer's failure to convey to the association such additional lands or facilities. 

(6) Notwithstanding other provisions of this chapter, any amendment by the developer which adds any land to the condominium shall be consistent with the provisions of the declaration granting such right and shall contain or provide for the following matters: 

 (a) A statement submitting the additional land to condominium ownership as an addition to the condominium. 

 (b) The legal description of the land being added to the condominium. 

 (c) An identification by letter, name, or number, or a combination thereof, of each unit within the land added to the condominium, to ensure that no unit in the condominium, including the additional land, will bear the same designation as any other unit. 

 (d) A survey of the additional land and a graphic description of the improvements in which any units are located and a plot plan thereof and a certificate of a surveyor. 

 (e) The undivided share in the common elements appurtenant to each unit in the condominium, stated as a percentage or fraction which, in the aggregate, must equal the whole and must be determined in conformance with the manner of allocation set forth in the original declaration of condominium. 

 (f) The proportion or percentage of, and the manner of sharing, common expenses and owning common surplus, which for a residential unit must be the same as the undivided share in the common elements. An amendment which adds phases to a condominium does not require the execution of such amendment or consent thereto by unit owners other than the developer. 

(7) An amendment to the declaration of condominium which adds land to the condominium shall be recorded in the public records where the land is located and shall be executed and acknowledged in compliance with the same requirements as for a deed. All persons who have record title to the interest in the land submitted to condominium ownership, or their lawfully authorized agents, must join in the execution of the amendment. 

(9) Upon recording the declaration of condominium or amendments adding phases pursuant to this section, the developer shall file the recording information with the Bureau within 120 calendar days on a form prescribed by the Bureau. 

§ 954. Mixed-use condominiums. When a condominium consists of both residential and commercial units, the following provisions shall apply: 

(1) The condominium documents shall not provide that the owner of any commercial unit shall have the authority to veto amendments to the declaration, articles of incorporation, bylaws, or rules or regulations of the association. 

(2) Subject to § 940 above, where the number of residential units in the condominium equals or exceeds 50 percent of the total units operated by the association, owners of the residential units shall be entitled to vote for a majority of the seats on the board of administration. 

(3) In the declaration of condominium for mixed-use condominiums, the ownership share of the common elements assigned to each unit shall be based either on the total square footage of each unit in uniform relationship to the total square footage of each other unit in the condominium or on an equal fractional basis. 

§ 955. Multicondominiums; multicondominium associations. 
(1) An association may operate more than one condominium if the declaration for each condominium to be operated by that association provides for participation in a multicondominium, in conformity with this section, and discloses or describes: 

(a) The manner or formula by which the assets, liabilities, common surplus, and common expenses of the association will be apportioned among the units within the condominiums operated by the association. 

(b) Whether unit owners in any other condominium, or any other persons, will or may have the right to use recreational areas or any other facilities or amenities that are common elements of the condominium, and, if so, the specific formula by which the other users will share the common expenses related to those facilities or amenities. 

(c) Recreational and other commonly used facilities or amenities which the developer has committed to provide that will be owned, leased by, or dedicated by a recorded plat to the association but which are not included within any condominium operated by the association. The developer may reserve the right to add additional facilities or amenities if the declaration and prospectus for each condominium to be operated by the association contains the following statement in conspicuous type and in substantially the following form: RECREATIONAL FACILITIES MAY BE EXPANDED OR ADDED WITHOUT CONSENT OF UNIT OWNERS OR THE ASSOCIATION. 

(d) The voting rights of the unit owners in the election of directors and in other multicondominium association affairs when a vote of the owners is taken, including, but not limited to, a statement as to whether each unit owner will have a right to personally cast his or her own vote in all matters voted upon. 

(2) If any declaration requires a developer to convey additional lands or facilities to a multicondominium association and the developer fails to do so within the time specified, or within a reasonable time if none is specified in the declaration, any unit owner or the association may enforce that obligation against the developer or bring an action against the developer for specific performance or for damages that result from the developer's failure or refusal to convey the additional lands or facilities. 

(3) The declaration for each condominium to be operated by a multicondominium association may not, at the time of the initial recording of the declaration, contain any provision with respect to allocation of the association's assets, liabilities, common surplus, or common expenses which is inconsistent with this chapter or the provisions of a declaration for any other condominium then being operated by the multicondominium association.

(4) This section does not prevent or restrict the formation of a multicondominium by the merger or consolidation of two or more condominium associations. Mergers or consolidations of associations shall be accomplished in accordance with this chapter and the declarations of the condominiums being merged or consolidated. 

§§ 956-959. [Reserved] 
 PART VI 
REGULATION AND DISCLOSURE PRIOR TO SALE OF RESIDENTIAL CONDOMINIUMS 

§ 960. Powers and duties of Bureau of Commercial Development. 
(1) The Bureau of Commercial Development, referred to as the "Bureau" in this part, has the power to enforce and ensure compliance with the provisions of this chapter and rules promulgated pursuant hereto relating to the development, construction, sale, lease, ownership, operation, and management of residential condominium units. In performing its duties, the division has the following powers and duties: 

(a) The Bureau may make necessary public or private investigations to determine whether any person has violated this chapter or any rule or order hereunder, to aid in the enforcement of this chapter, or to aid in the adoption of rules or forms hereunder. 

(b) The Bureau may require or permit any person to file a statement in writing, under oath or otherwise, as the Bureau determines, as to the facts and circumstances concerning a matter to be investigated. 

(c) For the purpose of any investigation under this chapter, the Bureau director or any officer or employee designated by the Bureau director may administer oaths or affirmations, subpoena witnesses and compel their attendance, take evidence, and require the production of any matter which is relevant to the investigation, including the existence, description, nature, custody, condition, and location of any books, documents, or other tangible things and the identity and location of persons having knowledge of relevant facts or any other matter reasonably calculated to lead to the discovery of material evidence. Upon the failure by a person to obey a subpoena or to answer questions propounded by the investigating officer and upon reasonable notice to all persons affected thereby, the division may apply to the circuit court for an order compelling compliance. 

(d) Notwithstanding any remedies available to unit owners and associations, if the Bureau has reasonable cause to believe that a violation of any provision of this chapter or rule promulgated pursuant hereto has occurred, the Bureau may institute enforcement proceedings in its own name against any developer, association, officer, or member of the board of administration, or its assignees or agents, as follows: 

1. The Bureau may permit a person whose conduct or actions may be under investigation to waive formal proceedings and enter into a consent proceeding whereby orders, rules, or letters of censure or warning, whether formal or informal, may be entered against the person. 

2. The Bureau may issue an order requiring the developer, association, officer, or member of the board of administration, or its assignees or agents, to cease and desist from the unlawful practice and take such affirmative action as in the judgment of the Bureau will carry out the purposes of this chapter. Such affirmative action may include, but is not limited to, an order requiring a developer to pay moneys determined to be owed to a condominium association. 

3. The Bureau may bring an action in court on behalf of a class of unit owners, lessees, or purchasers for declaratory relief, injunctive relief, or restitution. 

4. The Bureau may impose a civil penalty against a developer or association, or its assignee or agent, for any violation of this chapter or a rule promulgated pursuant hereto. The Bureau may impose a civil penalty individually against any officer or board member who willfully and knowingly violates a provision of this chapter, a rule adopted pursuant hereto, or a final order of the division. The term "willfully and knowingly" means that the Bureau informed the officer or board member that his or her action or intended action violates this chapter, a rule adopted under this chapter, or a final order of the bureau and that the officer or board member refused to comply with the requirements of this chapter, a rule adopted under this chapter, or a final order of the division. The Bureau, prior to initiating formal agency action, shall afford the officer or board member an opportunity to voluntarily comply with this chapter, a rule adopted under this chapter, or a final order of the Bureau. An officer or board member who complies within ten days is not subject to a civil penalty. A penalty may be imposed on the basis of each day of continuing violation, but in no event shall the penalty for any offense exceed $5,000. By January 1, 2011, the Bureau shall adopt, by rule, penalty guidelines applicable to possible violations or to categories of violations of this chapter or rules adopted by the division. The guidelines must specify a meaningful range of civil penalties for each such violation of the statute and rules and must be based upon the harm caused by the violation, the repetition of the violation, and upon such other factors deemed relevant by the division. For example, the Bureau may consider whether the violations were committed by a developer or owner-controlled association, the size of the association, and other factors. The guidelines must designate the possible mitigating or aggravating circumstances that justify a departure from the range of penalties provided by the rules. It is the legislative intent that minor violations be distinguished from those which endanger the health, safety, or welfare of the condominium residents or other persons and that such guidelines provide reasonable and meaningful notice to the public of likely penalties that may be imposed for proscribed conduct. This subsection does not limit the ability of the Bureau to informally dispose of administrative actions or complaints by stipulation, agreed settlement, or consent order. All amounts collected shall be deposited with the Bureau of Commercial Development. If a developer fails to pay the civil penalty, the Bureau shall thereupon issue an order directing that such developer cease and desist from further operation until such time as the civil penalty is paid or may pursue enforcement of the penalty in a court of competent jurisdiction. If an association fails to pay the civil penalty, the Bureau shall thereupon pursue enforcement in a court of competent jurisdiction, and the order imposing the civil penalty or the cease and desist order will not become effective until 20 days after the date of such order. 

(e) The Bureau is authorized to prepare and disseminate a prospectus and other information to assist prospective owners, purchasers, lessees, and developers of residential condominiums in assessing the rights, privileges, and duties pertaining thereto. 

(f) Within 180 days of the effective date of this Act, the Bureau shall adopt rules and regulations pursuant to the Administrative Procedure Act to implement and enforce the provisions of this chapter. 

(g) The Bureau shall establish procedures for providing notice to an association when the Bureau is considering the issuance of a declaratory statement with respect to the declaration of condominium or any related document governing in such condominium community. 

(h) When a complaint is made, the Bureau shall conduct its inquiry with due regard to the interests of the affected parties. Within 30 days after receipt of a complaint, the Bureau shall acknowledge the complaint in writing and notify the complainant whether the complaint is within the jurisdiction of the Bureau and whether additional information is needed by the Bureau from the complainant. The division shall conduct its investigation and shall, within 90 days after receipt of the original complaint or of timely requested additional information, take action upon the complaint. However, the failure to complete the investigation within 90 days does not prevent the Bureau from continuing the investigation, accepting or considering evidence obtained or received after 90 days, or taking administrative action if reasonable cause exists to believe that a violation of this chapter or a rule of the Bureau has occurred. If an investigation is not completed within the time limits established in this paragraph, the Bureau shall, on a monthly basis, notify the complainant in writing of the status of the investigation. When reporting its action to the complainant, the division shall inform the complainant of any right to a hearing pursuant to law. 

(2)	 (a) Each condominium association which operates more than two units shall pay to the Bureau an annual fee, which is not a property tax, in the amount of $4.00 for each residential unit in condominiums operated by the association. If the fee is not paid by March 1, then the association shall be assessed a penalty of ten percent of the amount due, and the association will not have standing to maintain or defend any action in the courts of the Republic of Palau until the amount due, plus any penalty, is paid. 

 (b) All fees shall be deposited with the Bureau of Commercial Development as provided by law. 

§ 961. Filing prior to sale or lease. 
(1) 	(a) A developer of a residential condominium or mixed-use condominium shall file with the Bureau one copy of each of the documents and items required to be furnished to a buyer or lessee by § 962 and § 963 below, if applicable. Until the developer has so filed, a contract for sale of a unit or lease of a unit for more than five years shall be voidable by the purchaser or lessee prior to the closing of his or her purchase or lease of a unit. 
 
(b) A developer may not close on any contract for sale or contract for a lease period of more than five years until the developer prepares and files with the Bureau documents complying with the requirements of this chapter and the rules adopted by the Bureau and until the Bureau notifies the developer that the filing is proper and the developer prepares and delivers all documents required by § 962(1)(b) below to the prospective buyer. 

 (c) The Bureau by rule may develop filing, review, and examination requirements and relevant timetables to ensure compliance with the notice and disclosure provisions of this section. 

(2)	 (a) Prior to filing as required by subsection (1), and prior to acquiring an ownership, leasehold, or contractual interest in the land upon which the condominium is to be developed, a developer shall not offer a contract for purchase of a unit or lease of a unit for more than five years. However, the developer may accept deposits for reservations upon the approval of a fully executed escrow agreement and reservation agreement form properly filed with the Bureau of Commercial Development. Each filing of a proposed reservation program shall be accompanied by a filing fee of $250. Reservations shall not be taken on a proposed condominium unless the developer has an ownership, leasehold, or contractual interest in the land upon which the condominium is to be developed. The Bureau shall notify the developer within 20 days of receipt of the reservation filing of any deficiencies contained therein. Such notification shall not preclude the determination of reservation filing deficiencies at a later date, nor shall it relieve the developer of any responsibility under the law. The escrow agreement and the reservation agreement form shall include a statement of the right of the prospective purchaser to an immediate unqualified refund of the reservation deposit moneys upon written request to the escrow agent by the prospective purchaser or the developer. 

 (b) The executed escrow agreement signed by the developer and the escrow agent shall contain the following information: 

1. A statement that the escrow agent will grant a prospective purchaser an immediate, unqualified refund of the reservation deposit moneys upon written request either directly to the escrow agent or to the developer. 

2. A statement that the escrow agent is responsible for not releasing moneys directly to the developer except as a down payment on the purchase price at the time a contract is signed by the purchaser if provided in the contract. 

 (c) The reservation agreement form shall include the following: 

1. A statement of the obligation of the developer to file condominium documents with the Bureau prior to entering into a binding purchase agreement or binding agreement for a lease of more than five years. 

2. A statement of the right of the prospective purchaser to receive all condominium documents as required by this chapter. 

3. The name and address of the escrow agent. 

4. A statement as to whether the developer assures that the purchase price represented in or pursuant to the reservation agreement will be the price in the contract for purchase and sale or that the price represented may be exceeded within a stated amount or percentage or that no assurance is given as to the price in the contract for purchase or sale. 

5. A statement that the deposit must be payable to the escrow agent and that the escrow agent must provide a receipt to the prospective purchaser. 

(3) Upon filing as required by subsection (1), the developer shall pay to the Bureau a filing fee of $20 for each residential unit to be sold by the developer which is described in the documents filed. If the condominium is to be built or sold in phases, the fee shall be paid prior to offering for sale units in any subsequent phase. Every developer who holds a unit or units for sale in a condominium shall submit to the Bureau any amendments to documents or items on file with the Bureau and deliver to purchasers all amendments prior to closing, but in no event, later than ten days after the amendment. Upon filing of amendments to documents currently on file with the Bureau, the developer shall pay to the Bureau a filing fee of up to $100 per filing, with the exact fee to be set by Bureau rate. 

(4) Any developer who complies with this section is not required to file with any other agency for approval to sell the units in the condominium, the information for the condominium for which he or she filed. 

(5) In addition to those disclosures described by § 962 and § 963 below, the Bureau is authorized to require such other disclosure as deemed necessary to fully or fairly disclose all aspects of the offering. 

§ 962. Developer disclosure prior to sale; nondeveloper unit owner disclosure prior to sale; voidability. 
(1) DEVELOPER DISCLOSURE. 

(a) Contents of contracts. Any contract for the sale of a residential unit or a lease thereof for an unexpired term of more than five years shall: 

1. Contain the following legend in conspicuous type: THIS AGREEMENT IS VOIDABLE BY BUYER BY DELIVERING WRITTEN NOTICE OF THE BUYER'S INTENTION TO CANCEL WITHIN 15 DAYS AFTER THE DATE OF EXECUTION OF THIS AGREEMENT BY THE BUYER, AND RECEIPT BY BUYER OF ALL OF THE ITEMS REQUIRED TO BE DELIVERED TO HIM OR HER BY THE DEVELOPER UNDER SECTION 962, OF TITLE 39 PALAU NATIONAL CODE. THIS AGREEMENT IS ALSO VOIDABLE BY BUYER BY DELIVERING WRITTEN NOTICE OF THE BUYER'S INTENTION TO CANCEL WITHIN 15 DAYS AFTER THE DATE OF RECEIPT FROM THE DEVELOPER OF ANY AMENDMENT WHICH MATERIALLY ALTERS OR MODIFIES THE OFFERING IN A MANNER THAT IS ADVERSE TO THE BUYER. ANY PURPORTED WAIVER OF THESE VOIDABILITY RIGHTS SHALL BE OF NO EFFECT. BUYER MAY EXTEND THE TIME FOR CLOSING FOR A PERIOD OF NOT MORE THAN 15 DAYS AFTER THE BUYER HAS RECEIVED ALL OF THE ITEMS REQUIRED. BUYER'S RIGHT TO VOID THIS AGREEMENT SHALL TERMINATE AT CLOSING. 

2. Contain the following caveat in conspicuous type on the first page of the contract: ORAL REPRESENTATIONS CANNOT BE RELIED UPON AS CORRECTLY STATING THE REPRESENTATIONS OF THE DEVELOPER. FOR CORRECT REPRESENTATIONS, REFERENCE SHOULD BE MADE TO THIS CONTRACT AND THE DOCUMENTS REQUIRED BY SECTION 962 OF TITLE 39, PALAU NATIONAL CODE, TO BE FURNISHED BY A DEVELOPER TO A BUYER OR LESSEE. 

3. If the unit has been occupied by someone other than the buyer, contain a statement that the unit has been occupied. 

4. If the contract is for the sale or transfer of a unit subject to a lease, include as an exhibit a copy of the executed lease and shall contain within the text in conspicuous type: THE UNIT IS SUBJECT TO A LEASE (OR SUBLEASE). 

5. If the contract is for the lease of a unit for a term of five years or more, include as an exhibit a copy of the proposed lease. 

6. If the contract is for the sale or lease of a unit that is subject to a lien for rent payable under a lease of a recreational facility or other commonly used facility, contain within the text the following statement in conspicuous type: THIS CONTRACT IS FOR THE TRANSFER OF A UNIT THAT IS SUBJECT TO A LIEN FOR RENT PAYABLE UNDER A LEASE OF COMMONLY USED FACILITIES. FAILURE TO PAY RENT MAY RESULT IN FORECLOSURE OF THE LIEN. 

7. State the name and address of the escrow agent required by § 930 above and state that the purchaser may obtain a receipt for his or her deposit from the escrow agent upon request. 

 (b) Copies of documents to be furnished to prospective buyer or lessee.--Until such time as the developer has furnished the documents listed below to a person who has entered into a contract to purchase a residential unit or lease it for more than five years, the contract may be voided by that person, entitling the person to a refund of any deposit together with interest thereon as provided in § 930 above. The contract may be terminated by written notice from the proposed buyer or lessee delivered to the developer within 15 days after the buyer or lessee receives all of the documents required by this section. The developer may not close for 15 days following the execution of the agreement and delivery of the documents to the buyer as evidenced by a signed receipt for documents unless the buyer is informed in the 15-day voidability period and agrees to close prior to the expiration of the 15 days. The developer shall retain in his or her records a separate agreement signed by the buyer as proof of the buyer's agreement to close prior to the expiration of said voidability period. Said proof shall be retained for a period of five years after the date of the closing of the transaction. The documents to be delivered to the prospective buyer are the prospectus or disclosure statement with all exhibits, if the development is subject to the provisions of § 963 below, or, if not, then copies of the following which are applicable: 

1. The question and answer sheet described in § 963, and declaration of condominium, or the proposed declaration if the declaration has not been recorded, which shall include the certificate of a surveyor approximately representing the locations required by § 903 above. 

2. The documents creating the association. 

3. The bylaws. 

4. The ground lease or other underlying lease of the condominium.

5. The management contract, maintenance contract, and other contracts for management of the association and operation of the condominium and facilities used by the unit owners having a service term in excess of one year, and any management contracts that are renewable. 

6. The estimated operating budget for the condominium and a schedule of expenses for each type of unit, including fees assessed pursuant to § 912(1) above for the maintenance of limited common elements where such costs are shared only by those entitled to use the limited common elements. 

7. The lease of recreational and other facilities that will be used only by unit owners of the subject condominium. 

8. The lease of recreational and other common facilities that will be used by unit owners in common with unit owners of other condominiums. 

9. The form of unit lease if the offer is of a leasehold. 

10. Any declaration of servitude of properties serving the condominium but not owned by unit owners or leased to them or the association. 

11. If the development is to be built in phases or if the association is to manage more than one condominium, a description of the plan of phase development or the arrangements for the association to manage two or more condominiums. 

12. The form of agreement for sale or lease of units. 

13. A copy of the floor plan of the unit and the plot plan showing the location of the residential buildings and the recreation and other common areas. 

14. A copy of all covenants and restrictions which will affect the use of the property and which are not contained in the foregoing. 

15. If the developer is required by law to obtain acceptance or approval of any dock or marina facilities intended to serve the condominium, a copy of any such acceptance or approval acquired by the time of filing with the Bureau under § 961(1), or a statement that such acceptance or approval has not been acquired or received. 

16. Evidence demonstrating that the developer has an ownership, leasehold, or contractual interest in the land upon which the condominium is to be developed. 

(2) NONDEVELOPER DISCLOSURE. 
 (a) Each unit owner who is not a developer as defined by this chapter shall comply with the provisions of this subsection prior to the sale of his or her unit. Each prospective purchaser who has entered into a contract for the purchase of a condominium unit is entitled, at the seller's expense, to a current copy of the declaration of condominium, articles of incorporation of the association, bylaws, and rules of the association, as well as a copy of the question and answer sheet provided for by § 963 below and a copy of the financial information required by § 909 above. 

 (b) If a real estate broker provides to or otherwise obtains for a prospective purchaser the documents described in this subsection, the person is not liable for any error or inaccuracy contained in the documents. 

 (c) Each contract entered into for the resale of a residential unit shall contain in conspicuous type either: 

1. A clause which states: THE BUYER HEREBY ACKNOWLEDGES THAT BUYER HAS BEEN PROVIDED A CURRENT COPY OF THE DECLARATION OF CONDOMINIUM, ARTICLES OF INCORPORATION OF THE ASSOCIATION, BYLAWS, RULES OF THE ASSOCIATION, A COPY OF THE MOST RECENT YEAR-END FINANCIAL INFORMATION AND THE QUESTION AND ANSWER SHEET MORE THAN 3 DAYS, EXCLUDING SATURDAYS, SUNDAYS, AND LEGAL HOLIDAYS, PRIOR TO EXECUTION OF THIS CONTRACT; or 

2. A clause which states: THIS AGREEMENT IS VOIDABLE BY BUYER BY DELIVERING WRITTEN NOTICE OF THE BUYER'S INTENTION TO CANCEL WITHIN 3 DAYS, EXCLUDING SATURDAYS, SUNDAYS, AND LEGAL HOLIDAYS, AFTER THE DATE OF EXECUTION OF THIS AGREEMENT BY THE BUYER AND RECEIPT BY BUYER OF A CURRENT COPY OF THE DECLARATION OF CONDOMINIUM, ARTICLES OF INCORPORATION, BYLAWS, AND RULES OF THE ASSOCIATION, A COPY OF THE MOST RECENT YEAR-END FINANCIAL INFORMATION AND QUESTION AND ANSWER SHEET IF SO REQUESTED IN WRITING. ANY PURPORTED WAIVER OF THESE VOIDABILITY RIGHTS SHALL BE OF NO EFFECT. THE BUYER MAY EXTEND THE TIME FOR CLOSING FOR A PERIOD OF NOT MORE THAN 3 DAYS, EXCLUDING SATURDAYS, SUNDAYS, AND LEGAL HOLIDAYS, AFTER THE BUYER RECEIVES THE DECLARATION, ARTICLES OF INCORPORATION, BYLAWS, RULES, AND QUESTION AND ANSWER SHEET IF REQUESTED IN WRITING. BUYER'S RIGHT TO VOID THIS AGREEMENT SHALL TERMINATE AT CLOSING. 

A contract that does not conform to the requirements of this paragraph is voidable at the option of the purchaser prior to closing. 

(3) OTHER DISCLOSURE. 

(a) If residential condominium parcels are offered for sale or lease prior to completion of construction of the units and of improvements to the common elements, or prior to completion of remodeling of previously occupied buildings, the developer shall make available to each prospective purchaser or lessee, for his or her inspection at a place convenient to the site, a copy of the complete plans and specifications for the construction or remodeling of the unit offered to him or her and of the improvements to the common elements appurtenant to the unit. 

(b) Sales brochures, if any, shall be provided to each purchaser, and the following caveat in conspicuous type shall be placed on the inside front cover or on the first page containing text material of the sales brochure, or otherwise conspicuously displayed: ORAL REPRESENTATIONS CANNOT BE RELIED UPON AS CORRECTLY STATING REPRESENTATIONS OF THE DEVELOPER. FOR CORRECT REPRESENTATIONS, MAKE REFERENCE TO THIS BROCHURE AND TO THE DOCUMENTS REQUIRED BY THIS CHAPTER TO BE FURNISHED BY A DEVELOPER TO A BUYER OR LESSEE.

§ 963. Prospectus or offering circular. Every developer of a residential condominium which contains more than 20 residential units, or which is part of a group of residential condominiums which will be served by property to be used in common by unit owners of more than 20 residential units, shall prepare a prospectus or offering circular and file it with the Bureau of Commercial Development prior to entering into an enforceable contract of purchase and sale of any unit or lease of a unit for more than five years and shall furnish a copy of the prospectus or offering circular to each buyer. In addition to the prospectus or offering circular, each buyer shall be furnished a separate page entitled "Frequently Asked Questions and Answers," which shall be in accordance with a format approved by the Bureau and a copy of the financial information required by § 909 above. This page shall, in readable language, inform prospective purchasers regarding their voting rights and unit use restrictions, including restrictions on the leasing of a unit; shall indicate whether and in what amount the unit owners or the association is obligated to pay rent or land use fees for recreational or other commonly used facilities; shall contain a statement identifying that amount of assessment which, pursuant to the budget, would be levied upon each unit type, exclusive of any special assessments, and which shall further identify the basis upon which assessments are levied, whether monthly, quarterly, or otherwise; shall state and identify any court cases in which the association is currently a party of record in which the association may face liability in excess of $100,000; and which shall further state whether membership in a recreational facilities association is mandatory, and if so, shall identify the fees currently charged per unit type. The Bureau shall by rate require such other disclosure as in its judgment will assist prospective purchasers. The prospectus or offering circular may include more than one condominium, although not all such units are being offered for sale as of the date of the prospectus or offering circular. The prospectus or offering circular must contain the following information: 

(l) The front cover or the first page must contain only: 

 (a) The name of the condominium. 

 (b) The following statements in conspicuous type: 

1. THIS PROSPECTUS (OFFERING CIRCULAR) CONTAINS IMPORTANT MATTERS TO BE CONSIDERED IN ACQUIRING A CONDOMINIUM UNIT. 

2. THE STATEMENTS CONTAINED HEREIN ARE ONLY SUMMARY IN NATURE. A PROSPECTIVE PURCHASER SHOULD REFER TO ALL REFERENCES, ALL EXHIBITS HERETO, THE CONTRACT DOCUMENTS, AND SALES MATERIALS. 

3. ORAL REPRESENTATIONS CANNOT BE RELIED UPON AS CORRECTLY STATING THE REPRESENTATIONS OF THE DEVELOPER. REFER TO THIS PROSPECTUS (OFFERING CIRCULAR) AND ITS EXHIBITS FOR CORRECT REPRESENTATIONS. 

(2) Summary: The next page must contain all statements required to be in conspicuous type in the prospectus or offering circular. 

(3) A separate index of the contents and exhibits of the prospectus. 

(4) Beginning on the first page of the text (not including the summary and index), a description of the condominium, including, but not limited to, the following information: 

 (a) Its name and location. 

 (b) A description of the condominium property, including, without limitation: 

l. The number of buildings, the number of units in each building, the number of bathrooms and bedrooms in each unit, and the total number of units, if the condominium is not a phase condominium, or the maximum number of buildings that may be contained within the condominium, the minimum and maximum numbers of units in each building, the minimum and maximum numbers of bathrooms and bedrooms that may be contained in each unit, and the maximum number of units that may be contained within the condominium, if the condominium is a phase condominium. 

2. The page in the condominium documents where a copy of the plot plan and survey of the condominium is located. 

3. The estimated latest date of completion of constructing, finishing, and equipping. In lieu of a date, the description shall include a statement that the estimated date of completion of the condominium is in the purchase agreement and a reference to the article or paragraph containing that information. 

 (c) The maximum number of units that will use facilities in common with the condominium. If the maximum number of units will vary, a description of the basis for variation and the minimum amount of dollars per unit to be spent for additional recreational facilities or enlargement of such facilities. If the addition or enlargement of facilities will result in a material increase of a unit owner's maintenance expense or rental expense, if any, the maximum increase and limitations thereon shall be stated. 

(5) A statement in conspicuous type describing whether the condominium is created and being sold as fee simple interests or as leasehold interests. If the condominium is created or being sold on a leasehold, the location of the lease in the disclosure materials shall be stated. 

(6) A description of the recreational and other commonly used facilities that will be used only by unit owners of the condominium, including, but not limited to, the following: 

 (a) Each room and its intended purposes, location, approximate floor area, and capacity in numbers of people. 

 (b) Each swimming pool, as to its general location, approximate size and depths, approximate deck size and capacity, and whether heated. 

 (c) Additional facilities, as to the number of each facility, its approximate location, approximate size, and approximate capacity. 

 (d) A general description of the items of personal property and the approximate number of each item of personal property that the developer is committing to furnish for each room or other facility or, in the alternative, a representation as to the minimum amount of expenditure that will be made to purchase the personal property for the facility. [sic](e) The estimated date when each room or other facility will be available for use by the unit owners. 

(f) 	1. An identification of each room or other facility to be used by unit owners that will not be owned by the unit owners or the association; 

 2. A reference to the location in the disclosure materials of the lease or other agreements providing for the use of those facilities; and

 3. A description of the terms of the lease or other agreements, including the length of the term; the rent payable, directly or indirectly, by each unit owner, and the total rent payable to the lessor, stated in monthly and annual amounts for the entire term of the lease; and a description of any option to purchase the property leased under any such lease, including the time the option may be exercised, the purchase price or how it is to be determined, the manner of payment, and whether the option may be exercised for a unit owner's share or only as to the entire leased property. 

 (g) A statement as to whether the developer may provide additional facilities not described above; their general locations and types; improvements or changes that may be made; the approximate dollar amount to be expended; and the maximum additional common expense or cost to the individual unit owners that may be charged during the first annual period of operation of the modified or added facilities. Descriptions as to locations, areas, capacities, numbers, volumes, or sizes may be stated as approximations or minimums. 

(7) A description of the recreational and other facilities that will be used in common with other condominiums, community associations, or planned developments which require the payment of the maintenance and expenses of such facilities, either directly or indirectly, by the unit owners. The description shall include, but not be limited to, the following: 

 (a) Each building and facility committed to be built. 

 (b) Facilities not committed to be built except under certain conditions, and a statement of those conditions or contingencies. 

 (c) As to each facility committed to be built, or which will be committed to be built upon the happening of one of the conditions in paragraph (b), a statement of whether it will be owned by the unit owners having the use thereof or by an association or other entity which will be controlled by them, or others, and the location in the exhibits of the lease or other document providing for use of those facilities. 

 (d) An estimate of the year in which each facility will be available for use by the unit owners or, in the alternative, the maximum number of unit owners in the project at the time each of all of the facilities is committed to be completed. 

 (e) A general description of the items of personal property, and the approximate number of each item of personal property, that the developer is committing to furnish for each room or other facility or, in the alternative, a representation as to the minimum amount of expenditure that will be made to purchase the personal property for the facility. 

 (f) If there are leases, a description thereof, including the length of the term, the rent payable, and a description of any option to purchase. 

 Descriptions shall include location, areas, capacities, numbers, volumes, or sizes and may be stated as approximations or minimums. 

(8) Recreation lease or associated club membership: 

 (a) If any recreational facilities or other facilities offered by the developer and available to, or to be used by, unit owners are to be leased or have club membership associated, the following statement in conspicuous type shall be included: THERE IS A RECREATIONAL FACILITIES LEASE ASSOCIATED WITH THIS CONDOMINIUM; or, THERE IS A CLUB MEMBERSHIP ASSOCIATED WITH THIS CONDOMINIUM. There shall be a reference to the location in the disclosure materials where the recreation lease or club membership is described in detail. 

 (b) If it is mandatory that unit owners pay a fee, rent, dues, or other charges under a recreational facilities lease or club membership for the use of facilities, there shall be in conspicuous type the applicable statement: 

1. MEMBERSHIP IN THE RECREATIONAL FACILITIES CLUB IS MANDATORY FOR UNIT OWNERS; or 

2. UNIT OWNERS ARE REQUIRED, AS A CONDITION OF OWNERSHIP, TO BE LESSEES UNDER THE RECREATIONAL FACILITIES LEASE; or 

3. UNIT OWNERS ARE REQUIRED TO PAY THEIR SHARE OF THE COSTS AND EXPENSES OF MAINTENANCE, MANAGEMENT, UPKEEP, REPLACEMENT, RENT, AND FEES UNDER THE RECREATIONAL FACILITIES LEASE (OR THE OTHER INSTRUMENTS PROVIDING THE FACILITIES); or 

4. A similar statement of the nature of the organization or the manner in which the use rights are created, and that unit owners are required to pay. 

Immediately following the applicable statement, the location in the disclosure materials where the development is described in detail shall be stated. 

 (c) If the developer, or any other person other than the unit owners and other persons having use rights in the facilities, reserves, or is entitled to receive, any rent, fee, or other payment for the use of the facilities, then there shall be the following statement in conspicuous type: THE UNIT OWNERS OR THE ASSOCIATION(S) MUST PAY RENT OR LAND USE FEES FOR RECREATIONAL OR OTHER COMMONLY USED FACILITIES. 

Immediately following this statement, the location in the disclosure materials where the rent or land use fees are described in detail shall be stated. 

 (d) If, in any recreation format, whether leasehold, club, or other, any person other than the association has the right to a lien on the units to secure the payment of assessments, rent, or other exactions, there shall appear a statement in conspicuous type in substantially the following form: 

l. THERE IS A LIEN OR LIEN RIGHT AGAINST EACH UNIT TO SECURE THE PAYMENT OF RENT AND OTHER EXACTIONS UNDER THE RECREATION LEASE. THE UNIT OWNER'S FAILURE TO MAKE THESE PAYMENTS MAY RESULT IN FORECLOSURE OF THE LIEN; or 

2. THERE IS A LIEN OR LIEN RIGHT AGAINST EACH UNIT TO SECURE THE PAYMENT OF ASSESSMENTS OR OTHER EXACTIONS COMING DUE FOR THE USE, MAINTENANCE, UPKEEP, OR REPAIR OF THE RECREATIONAL OR COMMONLY USED FACILITIES. THE UNIT OWNER'S FAILURE TO MAKE THESE PAYMENTS MAY RESULT IN FORECLOSURE OF THE LIEN. 

Immediately following the applicable statement, the location in the disclosure materials where the lien or lien right is described in detail shall be stated. 

(9) If the developer or any other person has the right to increase or add to the recreational facilities at any time after the establishment of the condominium whose unit owners have use rights therein, without the consent of the unit owners or associations being required, there shall appear a statement in conspicuous type in substantially the following form: RECREATIONAL FACILITIES MAY BE EXPANDED OR ADDED WITHOUT CONSENT OF UNIT OWNERS OR THE ASSOCIATION(S). Immediately following this statement, the location in the disclosure materials where such reserved rights are described shall be stated. 

(10) A statement of whether the developer's plan includes a program of leasing units rather than selling them, or leasing units and selling them subject to such leases. If so, there shall be a description of the plan, including the number and identification of the units and the provisions and term of the proposed leases, and a statement in boldfaced type that: THE UNITS MAY BE TRANSFERRED SUBJECT TO A LEASE. 

(11) The arrangements for management of the association and maintenance and operation of the condominium property and of other property that will serve the unit owners of the condominium property, and a description of the management contract and all other contracts for these purposes having a term in excess of one year, including the following: 

 (a) The names of contracting parties. 

 (b) The term of the contract. 

 (c) The nature of the services included. 

 (d) The compensation, stated on a monthly and annual basis, and provisions for increases in the compensation. 

 (e) A reference to the volumes and pages of the condominium documents and of the exhibits containing copies of such contracts. 

Copies of all described contracts shall be attached as exhibits. If there is a contract for the management of the condominium property, then a statement in conspicuous type in substantially the following form shall appear, identifying the proposed or existing contract manager: THERE IS (IS TO BE) A CONTRACT FOR THE MANAGEMENT OF THE CONDOMINIUM PROPERTY WITH (NAME OF THE CONTRACT MANAGER). Immediately following this statement, the location in the disclosure materials of the contract for management of the condominium property shall be stated. 

(12) If the developer or any other person or persons other than the unit owners has the right to retain control of the board of administration of the association for a period of time which can exceed one year after the closing of the sale of a majority of the units in that condominium to persons other than successors or alternate developers, then a statement in conspicuous type in substantially the following form shall be included: THE DEVELOPER (OR OTHER PERSON) HAS THE RIGHT TO RETAIN CONTROL OF THE ASSOCIATION AFTER A MAJORITY OF THE UNITS HAVE BEEN SOLD. Immediately following this statement, the location in the disclosure materials where this right to control is described in detail shall be stated. 

(13) If there are any restrictions upon the sale, transfer, conveyance, or leasing of a unit, then a statement in conspicuous type in substantially the following form shall be included: THE SALE, LEASE, OR TRANSFER OF UNITS IS RESTRICTED OR CONTROLLED. Immediately following this statement, the location in the disclosure materials where the restriction, limitation, or control on the sale, lease, or transfer of units is described in detail shall be stated. 

(14) If the condominium is part of a phase project, the following information shall be stated: 

 (a) A statement in conspicuous type in substantially the following form: THIS IS A PHASE CONDOMINIUM. ADDITIONAL LAND AND UNITS MAY BE ADDED TO THIS CONDOMINIUM. Immediately following this statement, the location in the disclosure materials where the phasing is described shall be stated. 

 (b) A summary of the provisions of the declaration which provide for the phasing. 

 (c) A statement as to whether or not residential buildings and units which are added to the condominium may be substantially different from the residential buildings and units originally in the condominium. If the added residential buildings and units may be substantially different, there shall be a general description of the extent to which such added residential buildings and units may differ, and a statement in conspicuous type in substantially the following form shall be included: BUILDINGS AND UNITS WHICH ARE ADDED TO THE CONDOMINIUM MAY BE SUBSTANTIALLY DIFFERENT FROM THE OTHER BUILDINGS AND UNITS IN THE CONDOMINIUM. Immediately following this statement, the location in the disclosure materials where the extent to which added residential buildings and units may substantially differ is described shall be stated. 

 (d) A statement of the maximum number of buildings containing units, the maximum and minimum numbers of units in each building, the maximum number of units, and the minimum and maximum square footage of the units that may be contained within each parcel of land which may be added to the condominium. 

(15) If the condominium is or may become part of a multicondominium, the following information must be provided: 

 (a) A statement in conspicuous type in substantially the following form: THIS CONDOMINIUM IS (MAY BE) PART OF A MULTICONDOMINIUM DEVELOPMENT IN WHICH OTHER CONDOMINIUMS WILL (MAY) BE OPERATED BY THE SAME ASSOCIATION. Immediately following this statement, the location in the prospectus or offering circular and its exhibits where the multicondominium aspects of the offering are described must be stated. 

 (b) A summary of the provisions in the declaration, articles of incorporation, and bylaws which establish and provide for the operation of the multicondominium, including a statement as to whether unit owners in the condominium will have the right to use recreational or other facilities located or planned to be located in other condominiums operated by the same association, and the manner of sharing the common expenses related to such facilities. 

 (c) A statement of the minimum and maximum number of condominiums, and the minimum and maximum number of units in each of those condominiums, which will or may be operated by the association, and the latest date by which the exact number will be finally determined.

 (d) A statement as to whether any of the condominiums in the multicondominium may include units intended to be used for nonresidential purposes and the purpose or purposes permitted for such use. 

 (e) A general description of the location and approximate acreage of any land on which any additional condominiums to be operated by the association may be located. 

(16) A summary of the restrictions, if any, to be imposed on units concerning the use of any of the condominium property, including statements as to whether there are restrictions upon children and pets, and reference to the volumes and pages of the condominium documents where such restrictions are found, or if such restrictions are contained elsewhere, then a copy of the documents containing the restrictions shall be attached as an exhibit. 

(17) If there is any land that is offered by the developer for use by the unit owners and that is neither owned by them nor leased to them, the association, or any entity controlled by unit owners and other persons having the use rights to such land, a statement shall be made as to how such land will serve the condominium. If any part of such land will serve the condominium, the statement shall describe the land and the nature and term of service, and the declaration or other instrument creating such servitude shall be included as an exhibit. 

(18) The manner in which utility and other services, including, but not limited to, sewage and waste disposal, water supply, and storm drainage, will be provided and the person or entity furnishing them. 

(19) An explanation of the manner in which the apportionment of common expenses and ownership of the common elements has been determined. 

(20) An estimated operating budget for the condominium and the association, and a schedule of the unit owner's expenses shall be attached as an exhibit and shall contain the following information: 

 (a) The estimated monthly and annual expenses of the condominium and the association that are collected from unit owners by assessments. 

 (b) The estimated monthly and annual expenses of each unit owner for a unit, other than common expenses paid by all unit owners, payable by the unit owner to persons or entities other than the association, as well as to the association, including fees assessed pursuant to § 912(1) above for maintenance of limited common elements where such costs are shared only by those entitled to use the limited common element, and the total estimated monthly and annual expense. There may be excluded from this estimate expenses which are not provided for or contemplated by the condominium documents, including, but not limited to, the costs of private telephone; maintenance of the interior of condominium units, which is not the obligation of the association; maid or janitorial services privately contracted for by the unit owners; utility bills billed directly to each unit owner for utility services to his or her unit; insurance premiums other than those incurred for policies obtained by the condominium; and similar personal expenses of the unit owner. A unit owner's estimated payments for assessments shall also be stated in the estimated amounts for the times when they will be due. 

 (c) The estimated items of expenses of the condominium and the association, except as excluded under paragraph (b) 

 (d) The estimated amounts shall be stated for a period of at least twelve months and may distinguish between the period prior to the time unit owners other than the developer elect a majority of the board of administration and the period after that date. 

[sic](22) A schedule of estimated closing expenses to be paid by a buyer or lessee of a unit and a statement of whether title opinion or title insurance policy is available to the buyer and, if so, at whose expense. 

(23) The identity of the developer and the chief operating officer or principal directing the creation and sale of the condominium and a statement of its and his or her experience in this field. 

(24) Copies of the following, to the extent they are applicable, shall be included as exhibits: 

(a) The declaration of condominium, or the proposed declaration if the declaration has not been recorded. 

(b) The articles of incorporation creating the association. 

(c) The bylaws of the association. 

(d) The ground lease or other underlying lease of the condominium. 

(e) The management agreement and all maintenance and other contracts for management of the association and operation of the condominium and facilities used by the unit owners having a service term in excess of one year. 

(f) The estimated operating budget for the condominium and the required schedule of unit owners' expenses. 

(g) A copy of the floor plan of the unit and the plot plan showing the location of the residential buildings and the recreation and other common areas. 

(h) The lease of recreational and other facilities that will be used only by unit owners of the subject condominium. 

(I) The lease of facilities used by owners and others. 

(j) The form of unit lease, if the offer is of a leasehold or the form of deed, if the sale is fee simple. 

(k) A declaration of servitude of properties serving the condominium but not owned by unit owners or leased to them or the association. 

(l) The statement of condition of the existing building or buildings, if the offering is of units in an operation being converted to condominium ownership. 

(m) The statement of inspection for termite damage and treatment of the existing improvements, if the condominium is a conversion. 

(n) The form of agreement for sale or lease of units. 

(o) A copy of the agreement for escrow of payments made to the developer prior to closing. 

(p) A copy of the documents containing any restrictions on use of the property required by subsection (16). 

(25) A brief narrative description of the location and effect of all existing and intended easements located or to be located on the condominium property other than those described in the declaration. 

(26) If the developer is required by state or local authorities to obtain acceptance or approval of any dock or marina facilities intended to serve the condominium, a copy of any such acceptance or approval acquired by the time of filing with the Bureau under § 961(1) above or a statement that such acceptance or approval has not been acquired or received. 

(27) Evidence demonstrating that the developer has an ownership, leasehold, or contractual interest in the land upon which the condominium is to be developed. 

§ 964. Good faith effort to comply. If a developer, in good faith, has attempted to comply with the requirements of this part, and if, in fact, he or she has substantially complied with the disclosure requirements of this chapter, nonmaterial errors or omissions in the disclosure materials shall not be actionable. 

§ 965. Publication of false and misleading information. 
(1) Any person who, in reasonable reliance upon any material statement or information that is false or misleading and published by or under authority from the developer in advertising and promotional materials, including, but not limited to, a prospectus, the items required as exhibits to a prospectus, brochures, and newspaper advertising, pays anything of value toward the purchase of a condominium parcel located in the Republic of Palau shall have a cause of action to rescind the contract or collect damages from the developer for his or her loss prior to the closing of the transaction. After the closing of the transaction, the purchaser shall have a cause of action against the developer for damages under this section from the time of closing until one year after the date upon which the last of the events described in paragraphs (a) through (d) shall occur: 

(a) The closing of the transaction; 

(b) The first issuance by the applicable governmental authority of a certificate of occupancy or other evidence of sufficient completion of construction of the building containing the unit to allow lawful occupancy of the unit; 

(c) The completion by the developer of the common elements and such recreational facilities, whether or not the same are common elements, which the developer is obligated to complete or provide under the terms of the written contract or written agreement for purchase or lease of the unit; or 

(d) In the event there shall not be a written contract or agreement for sale or lease of the unit, then the completion by the developer of the common elements and such recreational facilities, whether or not the same are common elements, which the developer would be obligated to complete under any rule of law applicable to the developer's obligation. 

Under no circumstances shall a cause of action created or recognized under this section survive for a period of more than five years after the closing of the transaction. 

(2) In any action for relief under this section or under § 962, the prevailing party shall be entitled to recover reasonable attorney's fees. 

§ 966. Bureau of Commercial Development. All funds collected under this chapter and any amount paid for a fee or penalty under this chapter shall be deposited in the National Treasury to the credit of the Bureau of Commercial Development Trust in a separate, segregated account. 

Section 4. Effective Date. This Act shall take effect upon its approval by the President, or upon becoming law without such approval, except as otherwise provided by law. 

PASSED: October 28, 2010 
Approved this 17th day of November , 2010. 
 /s/ 
His Excellency Johnson Toribiong 
President, Republic of Palau